HomeMy WebLinkAboutCC AG PKT 2014-05-12 #E AGENDA STAFF REPORT
4
DATE: May 12, 2014
TO: Honorable Mayor and City Council
THRU: Jill R. Ingram, City Manager
FROM: Sean P. Crumby P.E., Director of Public Works
SUBJECT: LOCAL STREET RESURFACING PROJECT NO.
ST1402 - AWARD OF CONSTRUCTION CONTRACT
SUMMARY OF REQUEST:
That the City Council adopt Resolution No. 6460:
1. Approving Plans and Specifications for the Local Street Resurfacing
Project No. ST1402;
2. Awarding a contract for the Local Street Resurfacing Project No. ST1402
to R.J. Noble Company in the amount of$89,720;
3. Authorizing the City Manager to execute the contract and approve
changes in the amount of$5,000; and
4. Authorizing $5,000 for inspection and materials testing.
BACKGROUND AND ANALYSIS:
Each year the City of Seal Beach delivers Annual Local Street Resurfacing and
Annual Arterial Street Resurfacing construction projects. The streets that are
selected to be rehabilitated are identified in the City's adopted Pavement
Management Plan. This year's project was identified within the 2012 Pavement
Management Plan.
Typically, these two programs are constructed separately for a variety of
reasons. They can involve different construction activities in different locations of
the City and for planning purposes, and the City may want them to be
constructed at different times of the year. Another factor in separating the two
projects is that the Arterial program is often augmented with grant funding that
makes the projects more efficient to separate. This year, staff is securing grant
funding for Arterial Road Resurfacing and therefore, is delivering the Local Street
Resurfacing project separately.
The project consists of roadway grinding, full-depth replacement of damaged
areas, resurfacing the asphalt roadway and final striping. The roads to be
resurfaced are 14 Street and 15th Street.
Agenda Item — E
On April 24, 2014, the City Clerk's office received five (5) bids with the following
results:
Rank Contractor Total Bid
I RJ Noble $ 89,720.00
2 Hardy and Harper $ 95,000.00
3 All American Asphalt $ 97,960.00
4 Excel Paving $ 104,200.00
5 COPP Contracting $ 110,600.00
Based upon the references, qualifications, work experience and cost, staff
recommends selecting R.J. Noble Company as the lowest responsive bidder at
$89,720.00.
ENVIRONMENTAL IMPACT:
This project complies with all requirements of the California Environmental
Quality Act (CEQA) and is categorically exempt under section 15301 class 1 (c).
LEGAL ANALYSIS:
The City Attorney has reviewed and approved the City's standard Construction
Contract.
FINANCIAL IMPACT:
This project has $100,000 budgeted within the FY2013-14 Budget and Capital
Improvement Program as follows:
Design plans were prepared in-house. The award of construction contract is
$89,720.00 with R.J. Noble Company. An anticipated breakdown of funds
needed to complete this project is as follows:
Description Amount
Construction $ 89,720.00
Contingency $ 5,000.00
Construction Management $ 5,000.00
Total $ 99,720.00
Page 2
RECOMMENDATION:
That the City Council adopt Resolution No. 6460:
1. Approving Plans and Specifications for the Local Street Resurfacing
Project No. ST1402;
2. Awarding a contract for the Local Street Resurfacing Project No. ST1402
to R.J. Noble Company in the amount of$89,720;
3. Authorizing the City Manager to execute the contract and approve
changes in the amount of$5,000; and
4. Authorizing $5,000 for inspection and materials testing.
SUBMITTED BY* NOTED AND APPROVED:
Sean P. Crumby, PE A R. Ingram, City M
ager
Director of Public Works '.�q
Prepared by: David Spitz, Associate Engineer
Attachments:
A. Resolution No.6460
B. Agreement
C. Street Map
Page 3
RESOLUTION NUMBER
A RESOLUTION OF THE SEAL BEACH CITY COUNCIL
AWARDING THE CONSTRUCTION CONTRACT FOR LOCAL
STREET RESURFACING PROGRAM PROJECT NO.ST1402
THE SEAL BEACH CITY COUNCIL DOES HEREBY RESOLVE:
SECTION 1. The City Council approves the plans and specifications for the
Local Street Resurfacing Program Project No. ST14O2(''Pnoject").
SECTION 2. The Qb/ Council awards a contract for the Project to R.J. Noble
Company in the amount of$O9.72O.
SECTION 3. The City Council directs the City Manager to execute the contract
for the Project.
SECTION 4. The City Council authorizes the City Manager to approve
payments for additional work requests in connection with the
Project in the cumulative amount of55.000.
SECTION 5. The City Council authorizes $5.00O for inspections and mohaha|
testing for the Project.
SECTION 6. The City Clerk shall certify to the paomo0a and adoption of this
resolution.
PASSED. APPROVED and ADOPTED by the Seal Beach Qty Council at a
regular meeting held on the 121h day of _1May L , 2U14by the following vote:
AYES: Council Members:
NOES: Council Members:
ABSENT: Council Members:
ABSTAIN: Council Members:
Mayor
ATTEST:
City Clerk
STATE UFCALIFORNIA I
COUNTY OFORANGE ) GG
CITY OF SEAL BEACH �
|. Linda Devine, City Clerk ofthe City of Seal Baach, do hereby certify that the
foregoing resolution is the original copy of Resolution Number 6460 on file in
the office ofthe City Clerk, possed, approvod, and adopted by the S*e| Beach
City Council ata regular meeting held on the 121h_ day of_1 May, 2U14.
City Clerk
RECOMMENDATION:
That the City Council adopt Resolution No. xxxx:
1. Approving Plans and Specifications for the Local Street Resurfacing
Project No. ST1402;
2. Awarding a contract for the Local Street Resurfacing Project No. ST1402
to R.J. Noble Company in the amount of $89,720;
3. Authorizing the City Manager to execute the contract and approve
changes in the amount of$5,000; and
4. Authorizing $5,000 for inspection and materials testing.
SUBMITTED BY- NOTED AND APPROVED:
Sean P. Crumby PE Jim ngram, City "ager
Director of Public Works
Prepared by: David Spitz, Associate Engineer
Attachments:
A. Resolution No. 6460
B. Agreement
C. Street Map
Page 3
PUBLIC WORKS AGREEMENT
FOR LOCAL STREET RESURFACING
PROGRAM PROJECT
CIP NO. ST1402
between
0� SEA( B
\�paaoRgr�9�s
o Q
Q
9yCFER 2
��NTY,CP
City of Seal Beach
211 - 8th Street
Seal Beach, CA 90740
R.J. Noble Company
15505 E. Lincoln Avenue
Orange, CA 92865
(714) 637-1550
(714) 637-6321 - FAX
THIS AGREEMENT is made as of May 12, 2014 by and between the City of Seal
Beach, a California charter city ("City"), and R.J. Noble Company, a General Contractor
("Contractor").
1 of 9
RECITALS
A. WHEREAS, the City Council has approved the plans and specifications for
the Local Street Resurfacing Program Project CIP No. ST1402 ("Project") with respect
to design criteria; and
B. WHEREAS, Contractor has submitted a bid to City for the Project dated
April 24, 2014 in the amount of $89,720 ("Accepted Proposal" hereinafter). The
Accepted Proposal is attached hereto as Exhibit G and contains, among other things,
provisions defining the Project scope.
NOW, THEREFORE, in consideration of performance by the parties of the
mutual promises, covenants, and conditions herein contained, the parties hereto agree
as follows:
AGREEMENT
1. Contractor's Services.
1.1 Scope and Level of Services. For and in consideration of the
mutual promises set forth herein, and subject to the terms and conditions set forth in
this Agreement, Contractor shall perform and complete in good and workmanlike
manner all work ("Work") required by this Agreement and the documents listed in
Subsection 1.2 for the Project.
1.2 Contract Documents. The "Contract Documents" that comprise the
agreement between the City and the Contractor are the: Notice Inviting Bids,
Instructions to Bidders, Accepted Proposal, Non-Collusion Affidavit, Bid Schedule(s),
List of Subcontractors, Contractor's Industrial Safety Record, Contractor's Qualification
Statement, Bid Security Forms for Check or Bond, Specifications, General and Special
Provisions and documents referenced therein, all addenda as prepared prior to the date
of bid opening setting forth any modifications or interpretations of any of said
documents, this Agreement, Exhibits attached to this Agreement, including but not
limited to the Performance Bond (Exhibit A), Payment Bond (Exhibit B), Workers'
Compensation Insurance Certificate (Exhibit C), Insurance Endorsements (Exhibit D),
Acknowledgment of Penal and Civil Penalties Concerning Contractor Licensing Laws
(Exhibit E), Labor Law Requirements (Exhibit F), Accepted Proposal (Exhibit G) and any
and all supplemental agreements executed amending or extending the Work
contemplated and that may be required to complete the Work in a substantial and
acceptable manner. These Contract Documents are hereby incorporated into this
Agreement.
13 The Work shall be performed in accordance with the Plans,
Specifications and other Contract Documents. Contractor shall furnish at its own
expense all labor, materials, equipment and services necessary therefor, except such
labor, materials, equipment and services as are specified in the Contract Documents to
be furnished by City.
2 of 9
1.4 In the event of any material discrepancy between the express
provisions of this Agreement and the provisions of the other Contract Documents, the
provisions of this Agreement shall prevail.
2. Effective Date. This Agreement is effective as of May 12, 2014 (the
"Effective Date"), and shall remain in full force and effect until Contractor has rendered
the services required by this Agreement.
3. Payment. For performing and completing the Work in accordance with the
Contract Documents, City shall pay Contractor, in full compensation therefor, the
amount of $89,720, subject to any additions and deletions pursuant to the terms of the
Contract Documents. Said sum shall constitute payment in full for all work performed
hereunder, including, without limitation, all labor, materials, equipment, tools and
services used or incorporated in the Work, supervision, administration, overhead,
expenses and any and all other things required, furnished or incurred for completion of
the Work as specified in the Contract Documents. City shall make payments to
Contractor on account of the contract sum at the time, in the manner, and upon the
conditions specified in the' Contract Documents. The City Manger may authorize extra
work to fund unforeseen conditions up to the amount approved at the time of award by
the City Council. Payment for additional work in excess of this amount requires prior
City Council authorization.
4. Contractor's Personnel.
4.1 All Work shall be performed by Contractor or under Contractor's
direct supervision, and all personnel shall possess the qualifications, permits, and
licenses required by state and local law and by the Notice Inviting Bids/instructions to
Bidders to perform such Services, including, without limitation, a City of Seal Beach
business license as required by the Seal Beach Municipal Code.
4.2 Contractor shall be responsible for payment of all employees'
wages and benefits, and shall comply with all requirements pertaining to employer's
liability, workers' compensation, unemployment insurance, and Social Security.
Contractor shall fully comply with the workers' compensation law regarding Contractor
and Contractor's employees.
4.3 Contractor shall indemnify and hold harmless City and its elected
officials, officers, employees, servants, designated volunteers, and agents serving as
independent contractors in the role of city officials, from any and all liabilities, damages,
claims, costs and expenses of any nature to the extent arising from Contractor's alleged
violations of personnel practices.
4.4 Contractor is, and shall at all times remain as to City, a wholly
independent contractor. Contractor shall have no power to incur any debt, obligation, or
liability on behalf of City or otherwise act as an agent of City. Neither City nor any of its
agents shall have control over the conduct of Contractor or any of Contractor's
employees, except as set forth in this Agreement. Contractor shall not, at any time, or
3 of 9
in any manner, represent that it or any of its officers, agents, or employees are in any
manner employees of City. Contractor shall pay all required taxes on amounts paid to
Contractor under this Agreement, and indemnify and hold City harmless from any and
all taxes, assessments, penalties, and interest asserted against City by reason of the
work performed pursuant to this Agreement.
4.5 City shall have the right to offset against the amount of any fees
due to Contractor under this Agreement any amount due to City from Contractor as a
result of Contractor's failure to promptly pay to City any reimbursement or
indemnification arising under this Section 4.
5. Indemnification.
5.1 Contractor's Duty. Contractor shall defend, indemnify, and hold the
City, its elected officials, officers, employees, volunteers, agents, and those City agents
serving as independent contractors in the role of City officials (collectively
"Indemnitees") free and harmless from and against any and all claims (including, without
limitation, claims for bodily injury, death or damage to property), demands, obligations,
damages, actions, causes of action, suits, losses, bid protests, stop notices, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a "Claim," collectively, "Claims"), in any manner arising out of or incident to the
performance of the Agreement, including without limitation, the payment of all
consequential damages and attorneys' fees and other related costs and expenses,
Further, Contractor shall appoint competent defense counsel, at Contractor's own cost,
expense and risk, to defend any and all such suits, actions or other legal proceedings of
every kind arising out of or incident to the performance of the Agreement that may be
brought or instituted against Indemnitees. Contractor shall pay and satisfy any
judgment, award or decree that may be rendered against City or the other Indemnitees
in any such suit, action, or other legal proceeding arising out of or incident to the
performance of the Agreement. Contractor shall reimburse the City and the other
Indemnitees, for any and all legal expenses and costs incurred by each of them in
connection therewith or in enforcing the indemnity herein provided. Contractor's
obligation to indemnify shall not be restricted to insurance proceeds, if any, received by
Contractor or Indemnitees. This indemnity shall apply to all Claims and liability
regardless of whether any insurance policies are applicable.
5.2 Bid Protests. In addition to its obligations pursuant to Section 5.1,
Contractor shall reimburse the City for all attorneys' fees and costs incurred by City in
connection with, arising out of or incident to any bid protest.
5.3 City's Sole Negligence. Nothing in Section 5.1 shall be construed
to require Contractor to indemnify Indemnitees for that portion of any Claim to the extent
arising from the sole negligence or willful misconduct of the Indemnitees.
5.4 Nonwaiver of Rights. Indemnitees do not, and shall not, waive any
rights that they may possess against Contractor because of the acceptance by City, or
4 of 9
the deposit with City, of any insurance policy or certificate required pursuant to this
Agreement.
5.5 Waiver of Right of Subrogation. Contractor, on behalf of itself and
all parties claiming under or through it, hereby waives all rights of subrogation against
the Indemnitees, while acting within the scope of their duties, from all claims, losses,
and liabilities arising out of or incident to activities or operations performed by or on
behalf of the Indemnitor.
5.6 Survival. The provisions of this Section 5 shall Survive the
termination of the Agreement and are in addition to any other rights or remedies that
Indemnitees may have under the law. Payment is not required as a condition precedent
to an Indemnitee's right to recover under this indemnity provision, and an entry of
judgment against a Contractor shall be conclusive in favor of the Indemnitee's right to
recover under this indemnity provision.
6. Insurance.
6.1 Liability Insurance. Contractor shall procure and maintain in full
force and effect for the duration of this Agreement insurance against claims for injuries
to persons or damages to property which may arise from or in connection with the
performance of the services hereunder by Con-tractor, and its agents, representatives,
employees and subcontractors. The policy limits set forth below do not act as a
limitation upon the amount of indemnification to be provided by Contractor. Contractor
shall complete and execute the following documents attached as Exhibits hereto and
incorporated herein by this reference:
6.1.1 Exhibit D-1: Additional Insured Endorsement -
Commercial General Liability.
6.1.2 Exhibit D-2: Additional Insured Endorsement -
Automobile Liability.
6.1.3 Exhibit D-3: Additional Insured Endorsement.
6.2 Minimum Scope of Insurance. Unless otherwise approved by City,
coverage shall be at least as broad as:
6.2.1 Insurance Services Office Commercial General Liability
coverage (occurrence form CG 0001).
6.2.2 Insurance Services Office form number CA 0001 (Ed.
1/87) covering Automobile Liability, code 1 (any auto).
6.2.3 Insurance Services Office form number CG 20 10 11 85
(Ed. 11/85) covering Additional Insured—Owners, Lessees or Contactors (Form B).
5 of 9
6.2.4 Workers' Compensation insurance as required by the
State of California and Employer's Liability Insurance.
6.3 Minimum Limits of Insurance. Contractor shall maintain limits no
less than:
6.3.1 General Liability: $2,000,000 per occurrence and in the
aggregate for bodily injury, personal injury and property damage. Commercial General
Liability Insurance or other form with a general aggregate limit shall apply separately to
this Agreement or the general limit shall be twice the required occurrence limit.
6.3.2 Automobile Liability: $2,000,000 per occurrence for bodily
injury and property damage.
6.3.3 EmploVer's Liability: $1,000,000 per occurrence and in
the aggregate for bodily injury or disease and Workers' Compensation Insurance in the
amount required by law.
6.4 Deductibles and Self-insured Retentions. Contractor shall inform
City of any deductibles or self-insured retentions except with respect to any professional
liability insurance.
6.5 Other Insurance Provisions. The general liability and automobile
liability policies are to contain, or be endorsed to contain, the following provisions:
6.5.1 City, its officers, officials, employees, designated
volunteers and agents serving as independent contractors in the role of City officials,
are to be covered as additional insureds as respects: liability arising out of activities
performed by or on behalf of Contractor; products and completed operations of
Contractor; premises owned, occupied or used by Contractor; or automobiles owned,
leased, hired or borrowed by Contractor. The coverage shall contain no limitations on
the scope of protection afforded to City, its officers, officials, employees, designated
volunteers or agents serving as independent contractors in the role of City officials
which are not also limitations applicable to the named insured.
6.5.2 For any claims related to this Agreement, Contractor's
insurance coverage shall be primary insurance as respects City, its officers, officials,
employees, designated volunteers and agents serving as independent contractors in the
role of City officials. Any insurance or self-insurance maintained by City, their officers,
officials, employees, designated volunteers or agents serving as independent
contractors in the role of City officials shall be excess of Contractor's insurance and
shall not contribute with it.
6.5.3 Contractor's insurance shall apply separately to each
insured against whom claim is made or suit is brought, except with respect to the limits
of the insurer's liability.
6 of 9
6.5.4 Each insurance policy required by this Section 6 shall be
endorsed to state that coverage shall not be canceled or materially modified except
after 30 days prior written notice by first class mail has been given to City.
6.5.5 Each insurance policy, except for any professional
liability policy, required by this Section 6 shall expressly waive the insurer's right of
subrogation against City and its elected officials, officers, employees, servants,
attorneys, designated volunteers, and agents serving as independent contractors in the
role of city or agency officials.
6.6 Acceptability of Insurers. Insurance is to be placed with insurers
with a current A.M. Best's rating of no less than A:VllI unless waived in writing by City's
Risk Manager.
6.7 Verification of Coverage. All insurance coverages shall be
confirmed by execution of endorsements on forms approved by the City. The
endorsements are to be signed by a person authorized by that insurer to bind coverage
on its behalf. All endorsements are to be received and approved by City before
services commence. As an alternative to City forms, Contractor's insurer may provide
complete, certified copies of all required insurance policies, including endorsements
effecting the coverage required by these specifications.
7. Liquidated Damages. Should the Contractor fail to complete the project,
or any part thereof, in the time agreed upon in the Contract, the Contractor shall
reimburse the City for the additional expense and damage for each calendar day that
the Contract remains uncompleted after the Contract completion date. It is agreed that
the amount of such additional expense and damage incurred by reason of failure to
complete the Contract is the per them rate of $750.00 per calendar day. Such amount
is hereby agreed upon as liquidated damages for the loss to the City resulting from the
failure of the Contractor to complete the project within the allotted time and to the value
of the operation of the works dependent thereon. It is expressly understood and agreed
that this amount is a reasonable amount and is established in lieu of damages that are
incapable of calculation at the inception hereof-, and this amount is not to be considered
in the nature of a penalty. The City shall have the right to deduct such damages from
any amount due, or that may become due to the Contractor, or the amount of such
damages shall be due and collectible from the Contractor or the Contractor's Surety,
Progress payments made after the scheduled completion date shall not constitute a
waiver of liquidated damages.
8. Suspension. City may, in writing, order Contractor to suspend all or any
part of the Contractor's Services for the convenience of City or for work stoppages
beyond the control of City or Contractor. A suspension of the Services does not void
this Agreement.
9. Notices. Any notices, bills, invoices, or reports authorized or required by
this Agreement shall be in writing and shall be deemed received on (a) the day of
delivery if delivered by hand or overnight courier service during Contractor's and City's
7 of 9
regular business hours or by facsimile before or during Contractor's regular business
hours; or (b) on the third business day following deposit in the United States mail,
postage prepaid, to the addresses heretofore set forth in the Agreement, or to such
other addresses as the parties may, from time to time, designate in writing pursuant to
the provisions of this Section. All notices shall be addressed as follows:
If to City: City Clerk
City of Seal Beach
211-8th Street
Seal Beach, California 90740
Telephone: (562) 431-2527
Fax: (562) 493-9857
With a copy to:
Public Works Director
City of Seal Beach
211-8th Street
Seal Beach, California 90740
If to Contractor: R.J. Noble Company
15505 E. Lincoln Avenue
Orange, CA 92865
Telephone: (714) 637-1550
Fax: (714) 637-6321
Attn: Craig Porte
10. Non-Assignability; Subcontracting. Contractor shall not assign, transfer,
or subcontract any interest in this Agreement or the performance of any of Contractor's
obligations hereunder. Any attempt by Contractor to so assign, transfer, or subcontract
any rights, duties, or obligations arising hereunder shall be null, void and of no effect.
11. Compliance with Laws. Contractor shall comply with all applicable federal,
state and local laws, ordinances, codes and regulations in force at the time Contractor
performs the Services.
12. Non-Waiver of Terms, Rights and Remedies. Waiver by either party of
any one or more of the conditions of performance under this Agreement shall not be a
waiver of any other condition of performance under this Agreement. In no event shall
the making by City of any payment to Contractor constitute or be construed as a waiver
by City of any breach of covenant, or any default which may then exist on the part of
Contractor, and the making of any such payment by City shall in no way impair or
prejudice any right or remedy available to City with regard to such breach or default.
13. Attorneys' Fees. In the event that either party to this Agreement shall
commence any legal action or proceeding to enforce or interpret the provisions of this
Agreement, the prevailing party in such action or proceeding shall be entitled to recover
its costs of suit, including all attorneys' fees incurred in connection therewith.
8 of 9
14, Construction. The validity, interpretation, and performance of this
Agreement shall be controlled by and construed under the laws of the State of
California. In the event of any asserted ambiguity in, or dispute regarding the
interpretation of any matter herein, the interpretation of this Agreement shall not be
resolved by any rules of interpretation providing for interpretation against the party who
causes the uncertainty to exist or against the party who drafted the Agreement or who
drafted that portion of the Agreement.
15. Entire Agreement. This Agreement, including any other documents
incorporated herein by specific reference, represents the entire and integrated
agreement between Contractor and City. This Agreement supersedes all prior oral or
written negotiations, representations, or agreements. This Agreement may not be
amended, nor any provision or breach hereof waived, except in a writing signed by the
parties which expressly refers to this Agreement.
16. Severability. The invalidity in whole or in part of any provisions of this
Agreement shall not void or affect the validity of the other provisions of this Agreement.
IN WITNESS WHEREOF, the parties, through their respective authorized
representatives, have executed this Agreement as of the date first written above.
CITY OF SEAL BEACH CONTRACTOR:
By: By: x 4a� .�� -
Jill R. Ingram, City Manager
Name: MICHAEL J.CARVER
Attest:
Title: PRESIDENT
By:
Linda Devine, City Clerk
Name: x
Approved as to Form:
Title: STEVE MENDOZA,SECRETARY
By:
Quinn M. Barrow, City Attorney
9 of 9
EXHIBIT A
FAITHFUL PERFORMANCE BOND
EXHIBIT B
PAYMENT BOND
EXHIBIT C
WORKERS' COMPENSATION INSURANCE CERTIFICATE
EXHIBIT D-9
ADDITIONAL INSURED ENDORSEMENT
(COMMERCIAL GENERAL LIABILITY)
EXHIBIT D-2
ADDITIONAL INSURED ENDORSEMENT
(AUTOMOBILE LIABILITY)
EXHIBIT D-3
ADDITIONAL INSURED ENDORSEMENT
EXHIBIT E
ACKNOWLEDGMENT OF PENAL AND CIVIL PENALTIES CONCERNING
CONTRACTOR LICENSING LAWS
EXHIBIT F
LABOR LAW REQUIREMENTS
EXHIBIT G
ACCEPTED PROPOSAL
('NOTE: Exhibits will not be included with the contract at the
time of award. The Contractor shall have 90 working days to
submit all exhibits to the City after the award of contract. Failure
to do so will result in voiding of the contract, The City will then
have the right to cash the bid bond for the project and re-
advertise for construction or award to the next lowest
responsive bidder.)
o �
Pavement Map
qp3 CRYSTAL COVE WY aQ1 EMERALD COVE WY 2 y
p ^ r
a A
O QQ N M O 111
N M V O ;p 74 - OQ O N M O N M O j !> O�
Q =
m W
r
PACIFIC COAST HWY
v
1250 333
°o yQQ o pQQ pQQ ^oQQ 1600
1244 �2 331
361 328 326 327 328 325 328
326 325 326
364 357 324 325 324 323 323
323 324 323 321 322 321
360 355 322 319 320 321 322 319 322 321 319
320
317
335584 349 318 317 318 317 345 316 315 316 315 318 315
352 316 313 314 315 314 313 314 313 314 313
M �0 312 311 312 311 312 311 312 311
M 348 343 307 309 310 309 309
346 308 307 308 308 307 308
U) 344 341 306 305 306 305 306 305 306 305 306 307
= 342 N o 303 303 303
N 340 335 N 302 301 302 c°� c°n 301 302 301 1702
D
N LANDING AV
Cl)
334 229 234 237 242 243 N 248 249 255 260 m
332 225 r 240 = 252 253 258 U
233 238 239 F- 244 247 N 250 251 256 ^ Q
330
M 254 223 230 231 236 237 242 243 I— 249 CO) 254 N m
V 326 221 228 234 233 246 247 = 252 J
229 238 239 245 250 Q
244 t�
324 217 224 225 230 231 229 236 235 243 248 U)/
215 222 221 228 227 232 235 240 241 246
320
211 218 219 224 238 237
225 230 231
234
O1 209 214 215 222 221 226 227 235
n'� M 212 213 218 224 225 232 231
° o 211 217 228 229 233
N �
N N N r 209 214 220 221 226 227
212 213 219 224 5 41 231
211 216 222
N r
2 0 214 215 2220 Q 26
225 M � rn o M 213 224 2 211 222
209 223
220
j 202 213 218 219
AV 212 z119 214 215
160
(q No M � 212 213
158 1210 r 1515 N o M 211
X. o
156 155 V o o m 209
154 153 154 .4
151 152 1310 CTRL'AV
150
F- 149 150 n r
o N 147 148 147 148
2 146 145 146 146 ,Q
F- 144 143 2 143 144 141
142 �v
142
140 141 141 N 137 ] 138 G�
Cl) 138 = 140 135 Q
138 137 136 135 136 133 Z 134 7S2j 1532 y�pY 137 138 -
134 135 134 133 134 a 132 Z 15 1847
132 131 131 132 131 0 128 1528 1187 Q 163FL' RI
130 132 129 130 129 'F 1524 1s 3> Q2 1630 C AV
128 129 128 127 128 125 126 1522 18 35 O[[/ 11630 1638
126 125 126 125 126 123 120 1631 33 O 828 1635
Legend
;
Paving Location .na
s