Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
AGMT - LEED Electric Inc (On-Call Electrical Maintenance and Repair Services)
MAINTENANCE SERVICES AGREEMENT for On -Call Electrical Maintenance and Repair Services between City of Seal Beach 211 - 8th Street Seal Beach, CA 90740 9 LEED Electric, Inc. 13138 Artic Circle Santa Fe Springs, CA 90670 (562) 270-9500 This Maintenance Services Agreement ("the Agreement") is made as of December 13 2021 (the "Effective Date"), by and between LEED Electric, Inc., a California corporation ("Contractor"), and the City of Seal Beach ("City"), a California charter city,. (collectively, "the Parties"). RECITALS A. City desires certain on-call emergency and unexpected task electrical maintenance and repair services. B. Pursuant to the authority provided by its City Charter and Seal Beach Municipal Code § 3.20.025(C), City issued a Request for Proposals ("RFP") on September 15, 2021, titled "On -Call Electrical Maintenance and Repair Services." Contractor submitted a proposal dated October 7, 2021, in response to the RFP. C. Contractor represents that the principal members of its firm are qualified California licensed contractors License #379096, DIR 1000004633 and are fully qualified to perform the services contemplated by this Agreement by virtue of its experience, and the training, education and expertise of its principals and employees. D. City desires to retain Contractor as an independent contractor and Contractor desires to serve City to perform those services in accordance with the terms and conditions of this Agreement. NOW THEREFORE, in consideration of the Parties' performance of the promises, covenants, and conditions stated herein, the Parties hereto agree _ as follows. AGREEMENT 1.0 Scope of Services 1.1. Strictly on an on-call basis, Contractor shall provide those electrical maintenance and related repair services (collectively "Services") in the Request for Proposals attached hereto as Exhibit A, and Contractor's Proposal attached hereto as Exhibit B, and incorporated herein by this reference. To the extent that there is any conflict between Exhibit A, Exhibit B, and this Agreement, this Agreement shall control. Given the on-call nature of this Agreement, Contractor acknowledges that there is no guarantee that City shall request any Services hereunder. 1.2. Contractor shall perform all Services under this Agreement in accordance with the standard of care generally exercised by like professionals under similar circumstances and in a manner reasonably satisfactory to City. 1.3. In performing this Agreement, Contractor shall comply with all applicable provisions of federal, state, and local law. 1.4. As a material inducement to City to enter into this Agreement, Contractor hereby represents that it has the experience necessary to undertake 2of19 the Services to be provided. In light of such status and experience, Contractor hereby covenants that it shall follow the customary professional standards in performing all Services. The City relies upon the skill of Contractor, and Contractor's staff, if any, to do and perform the Services in a skillful, competent, and professional manner, and Contractor and Contractor's staff, shall perform the Services in such manner. Contractor shall, at all times; meet or exceed any and all applicable professional standards of care. The acceptance of Contractor's work by the City shall not operate as a release of Contractor from such standard of care and workmanship. 1.5. Contractor will not be compensated for any work performed not specified in the Scope of Services unless the City authorizes such work in advance and in writing. The City Manager may authorize extra work to fund unforeseen conditions up to the amount approved at the time of award by the City Council. Payment for additional work in excess of this amount requires prior City Council authorization. 2.0 Term 2.1. The term of this Agreement shall commence as of the Effective Date and shall continue for a term of three (3) years ("Original Term") and shall expire at midnight on December 13, 2024, unless sooner terminated or extended as provided by this Agreement. 2.2. The City, at its sole option, may elect to extend the Original Term of this Agreement, upon the same terms and conditions, for up to two (2) additional terms of one year each ("extension"), by providing written notice to Contractor at least one month prior to the expiration of an existing term. If timely elected by the City, the first extension shall have a term extending from December 13, 2024 through and including December 13, 2025, unless sooner terminated or extended pursuant to this Agreement. If timely elected by the City, the second extension shall be from December 13, 2025 through and including December 13, 2026, unless sooner terminated pursuant to this Agreement. Any extension shall not be effective except upon execution of a written amendment to this Agreement signed by the City Manager and Contractor's authorized representatives. 3.0 Contractor's Compensation 3.1. In consideration of Contractor's performance of the Services set forth in Exhibit A, City will pay Contractor in accordance with the hourly rates shown on the fee schedule set forth in Exhibit B for the Services but in no event will the City pay more than the total not -to -exceed amount of $300,000 (Three Hundred Thousand dollars and 00/100) for the Original Term. 3.2 Payment for any additional work authorized by the City pursuant to Section 1.5 will be compensated in accordance with the fee schedule set forth in 3of19 Exhibit B, and shall not exceed the cumulative amount established by the City Council at the time of award for the Original Term. 3.3. In the event that City elects to extend the Original Term in accordance with Section 2.2 of this Agreement, in consideration of Contractor's performance of the Services set forth in Exhibit A City will pay Contractor in accordance with the hourly rates shown on the fee schedule set forth in Exhibit B for Services but in no event will the City pay more than the total not -to -exceed amount of $100,000 (One Hundred Thousand dollars and 00/100) for each extension. Payment for any additional work authorized by City pursuant to Section 1.5 for each extension will be compensated in accordance with the fee schedule set forth in Exhibit B and shall not exceed the cumulative amount established by City at the time of award. 4.0 Method of Payment 4.1. Contractor shall submit to City monthly invoices for all Services rendered pursuant to this Agreement. Such invoices shall be submitted within 15 days of the end of the month during which the Services were rendered and shall describe in detail the Services rendered during the period, the days worked, number of hours worked, the hourly rates charged, and the Services performed for each day in the period. City will pay Contractor within 30 days of receiving Contractor's invoice. City will not withhold any applicable federal or state payroll and other required taxes, or other authorized deductions from payments made to Contractor. 4.2. Upon 24-hour notice from City, Contractor shall allow City or City's agents or representatives to inspect at Contractor's offices during reasonable business hours all records, invoices, time cards, cost control sheets and other records maintained by Contractor in connection with this Agreement. City's rights under this Section 4.2 shall survive for three (3) years following the termination of this Agreement. 5.0 Termination 5.1. This Agreement may be terminated by City, without cause, or by Contractor based on reasonable cause, upon giving the other party written notice thereof not less than 30 days prior to the date of termination. 5.2. This Agreement may be terminated by City upon 10 days' notice to Contractor if Contractor fails to provide satisfactory evidence of renewal or replacement of comprehensive general liability insurance as required by this Agreement at least 20 days before the expiration date of the previous policy. 4of19 6.0 Party Representatives 6.1. The City Manager is the City's representative for purposes of this Agreement. 6.2. Seyed A. Jamali Dinan .is the Contractor's primary representative for purposes of this Agreement. Seyed A. Jamali Dinan shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the Services hereunder. Contractor may not change its representative without the prior written approval of City, which appro6 shall not be unreasonably withheld. 7.0 Notices 7.1. All notices permitted or required under this Agreement shall be deemed made when personally delivered or when mailed 48 hours after deposit in the United States Mail, first class postage prepaid and addressed to the party at the following addresses: To City: City of Seal Beach 211 -8th Street Seal Beach, California 90740 Attn: City Manager To Contractor: LEED Electric, Inc. 13138 Artic Circle Santa Fe Springs CA 90670 Attn: Seyed A. Jamali Dinan 7.2. Actual notice shall be deemed adequate notice op the date actual notice occurred, regardless of the method of service. 8.0 Permits and Licenses Contractor and all of Contractor's employees and other personnel shall obtain and maintain during the Agreement term all necessary licenses, permits and certificates required by law for the provision of the Services under this Agreement, including a business license as required by the Seal Beach Municipal Code. 9.0 Independent Contractor 9.1. Contractor is an independent contractor and not an employee of the City. All work or other Services provided pursuant to this Agreement shall be performed by Contractor or by Contractor's employees or other personnel under Contractor's supervision. Contractor will determine the means, methods, and details by which Contractor's employees and other personnel will perform the 5of19 Services. Contractor shall be solely responsible for the satisfactory work performance of all personnel engaged in performing the Services and compliance with the customary professional standards. 9.2. All of Contractor's employees and other personnel performing any of the Services under this Agreement on behalf of Contractor shall also not be employees of City and shall at all times be under Contractor's exclusive direction and control. Contractor and Contractor's personnel shall not supervise any of City's employees; and City's employees shall not supervise Contractor's personnel. Contractor's personnel shall not wear or display any City uniform, badge, identification number, or other information identifying such individual as an employee of City; and Contractor's personnel shall not use any City e-mail address or City telephone number in the performance of any of the Services under this Agreement. Contractor shall acquire and maintain at its sole cost and expense such vehicles, equipment and supplies as Contractor's personnel require to perform any of the Services required by this Agreement. Contractor shall perform all Services off of City premises at locations of Contractor's choice, except (1) as otherwise required for the performance of Services on City real property, vehicles or equipment; (2) as otherwise may from time to time be necessary in order for Contractor's personnel to receive projects from City, review plans on file at City, pick up or deliver any work product related to Contractor's performance of any Services under this Agreement, or (3) as may be necessary to inspect or visit City locations and/or private property to perform such Services. City may make a computer available to Contractor from time to time for Contractor's personnel to obtain information about or to check on the status of projects pertaining to the Services under this Agreement. 9.3. Contractor shall be responsible for and pay all wages, salaries, benefits and other amounts due to Contractor's personnel in connection with their performance of any Services under this Agreement and as required by law. Contractor shall be responsible for all reports and obligations respecting such additional personnel, including, but not limited to: Social Security taxes, other retirement or pension benefits, income tax withholding, unemployment insurance, disability insurance, and workers' compensation insurance. Notwithstanding any other agency, State, or federal policy, rule, regulation, statute or ordinance to the contrary, Contractor and any of its officers, employees, agents, and subcontractors providing any of the Services under this Agreement shall not become entitled to, and hereby waive any claims to, any wages, salaries, compensation, benefit or any incident of employment by City, including but not limited to, eligibility to enroll in, or reinstate to membership in, the California Public Employees Retirement System ("PERS") as an employee of City, and entitlement to any contribution to be paid by City for employer contributions or employee contributions for PERS benefits. 9.4. Contractor shall indemnify and hold harmless City and its elected officials, officers, employees, servants, designated volunteers, and agents 6of19 serving as independent contractors in the role of City officials, from any and all liability, damages, claims, costs and expenses of any nature to the extent arising from, caused by, or relating to Contractor's personnel practices. or to the extent arising from, caused by or relating to the violation of any of the provisions of this Section 9.0. In addition to all other remedies available under law, City shall have the right to offset against the amount of any fees due to Contractor under this Agreement any amount due to City from Contractor as a result of Contractor's failure to promptly pay to City any reimbursement or indemnification arising under this Section. This duty of indemnification is in addition to Contractor's duty to defend, indemnify and hold harmless as set forth in any other provision of this Agreement. Contractor's indemnifications and obligations under this Section shall survive the expiration or termination of this Agreement. 10.0 PERS Compliance and Indemnification 10.1. General Requirements. The Parties acknowledge that City is a local agency member of PERS, and as such has certain pension reporting and contribution obligations to PERS on behalf of qualifying employees. Contractor agrees that, in providing its employees and any other personnel to City to perform any work or other Services under this Agreement, Contractor shall assure compliance with the Public Employees' Retirement Law ("PERE"), commencing at Government Code § 20000, as amended by the Public Employees' Pension Reform Act of 2013 ("PEPRA" ),. and the regulations of PERS. Without limitation to the foregoing, Contractor shall assure compliance with regard to personnel who have active or inactive membership in PERS and to those who are retired annuitants and in performing this Agreement shall not assign or utilize any of its personnel in a manner that will cause City to be in violation of the PERL, PEPRA or any other applicable retirement laws and regulations. 10.2. Indemnification. Contractor shall defend (with legal counsel approved by City, whose approval shall not be unreasonably withheld), indemnify and hold harmless City, and its City and its elected officials, officers, employees, servants, designated volunteers, and agents serving as independent contractors in the role of City officials, from any and all liability, damages, claims, costs and expenses of any nature to the extent arising from, caused by, or relating to Contractor's violation of any provisions of this Section 10.0. This duty of indemnification is in addition to Contractor's duty to defend, indemnify and hold harmless as set forth in any other provision of this Agreement. Contractor's indemnification and obligations under this Section shall survive the expiration or termination of this Agreement. 11.0 Confidentiality 11.1. Contractor covenants that all data, reports, documents, surveys, studies, drawings, plans, maps, models, photographs, images, video files, media, 7of19 discussion, or other information (collectively "Data & Documents") developed or received by Contractor or provided for performance of this Agreement are deemed confidential and shall not be disclosed by Contractor without prior written authorization by City. City shall grant such authorization if applicable law requires disclosure. Contractor, its officers, employees, agents, or subcontractors shall not without written authorization from the City Manager or unless requested in writing by the City Attorney, voluntarily provide declarations, letters of support, testimony at depositions, response to interrogatories or other information concerning the Services performed under this Agreement or relating to any project or property located within the City. Response to a subpoena or court order shall not be considered "voluntary," provided Contractor gives City notice of such court order or subpoena. 11.2. Contractor shall promptly notify City should Contractor, its officers, employees, agents or subcontractors be served with any summons, complaint, subpoena, notice of deposition, request for documents, interrogatories, request for admissions or other discovery request, court order or subpoena from any party regarding this Agreement and the work performed thereunder or with respect to any project or property located within the City. City may, but has no obligation to, represent Contractor or be present at any deposition, hearing or similar proceeding. Contractor agrees to cooperate fully with City and to provide City with the opportunity to review any response to discovery requests provided by Contractor. However, City's right to review any such response does not imply or mean the right by City to control, direct or rewrite the response. 11.3. Contractor's covenants under this Section shall survive the termination or expiration of this Agreement. 12.0 Ownership of Documents and Work Product 12.1. All Data & Documents shall be and remain the property of City without restriction or limitation upon its use, duplication or dissemination by City. All Data & Documents shall be considered "works made for hire," and all Data ,& Documents and any and all intellectual property rights arising from their creation, including, but not limited to, all copyrights and other proprietary rights, shall be and remain the property of City without restriction or limitation upon their use, duplication or dissemination by City. Contractor shall not obtain or attempt to obtain copyright protection as to any Data & Documents. 12.2. Contractor hereby assigns to City all ownership and any and all intellectual property rights to the Data & Documents that are not otherwise vested in City pursuant to the paragraph directly above this one. 12.3. Contractor warrants and represents that it has secured all necessary licenses, consents or approvals to use any instrumentality, thing or component as to which any intellectual property right exists, including computer 8of19 software, used in the rendering of the Services and the production of all Written Products produced under this Agreement, and that City has full legal title to and the right to reproduce the Data & Documents. Contractor shall defend, indemnify and hold City, and its elected officials, officers, employees, servants, attorneys, designated volunteers, and agents serving as independent contractors in the role of City officials, harmless from any loss, claim or liability in any way related to a claim that City's use of any of the Data & Documents is violating federal, state or local laws, or any contractual provisions, or any laws relating to trade names, licenses, franchises, copyrights, patents or other means of protecting intellectual property rights and/or interests in products or inventions. Contractor shall bear all costs arising from the use of patented, copyrighted, trade secret or trademarked documents, materials, equipment, devices or processes in connection with its provision of the Services and Data & Documents produced under this Agreement. In the event the use of any of the Written Products or other deliverables hereunder by City is held to constitute an infringement and the use of any of the same is enjoined, Contractor, at its expense, shall: (1) secure for City the right to continue using the Data & Documents and other deliverables by suspension of any injunction, or by procuring a license or licenses for City; or (2) modify the Data & Documents and other deliverables so that they become non - infringing while remaining in compliance with the requirements of this Agreement. These covenants shall survive the expiration and/or termination of this Agreement. 12.4. Upon expiration or termination of the Agreement, Contractor shall deliver to City all Data & Documents and other deliverables related to any Services performed pursuant to this Agreement without additional cost or expense to City. If Contractor prepares a document on a computer, Contractor shall provide City with said document both in a printed format and in an electronic format that is acceptable to City. 13.0 Subcontractors No portion of this Agreement shall be subcontracted without the prior written approval of the City. Contractor is fully responsible to City for the performance of any and all subcontractors. 14.0 Prohibition Against Assignment or Delegation Contractor shall not assign any of its rights or delegate any of its duties under this Agreement, either in whole or in part, without City's prior written consent. Any purported assignment or delegation in violation of this Section shall be void and without effect, and shall entitle City to terminate this Agreement. As used in this Section, "assignment' and "delegation" means any sale, gift, pledge, hypothecation, encumbrance or other transfer of all or any portion of the rights, obligations, or liabilities in or arising from this Agreement to any person or entity, 9of19 whether by operation of law or otherwise, and regardless of the legal form of the transaction in which the attempted transfer occurs. 15.0 Inspection and Audit of Records Contractor shall maintain complete and accurate records with respect to all Services and other matters covered under this Agreement, including but expressly not limited to, all Services performed, salaries, wages, invoices, time cards, cost control sheets, costs, expenses, receipts and other records with respect to this Agreement. Contractor shall maintain adequate records on the Services provided in sufficient detail to permit an evaluation of all Services in connection therewith. All such records shall be clearly identified and readily accessible. At all times during regular business hours, Contractor shall provide City with free access to such records, and the right to examine and audit the same and to make copies and transcripts as City deems necessary, and shall allow inspection of all program data, information, documents, proceedings and activities and all other matters related to the performance of the Services under this Agreement. Contractor shall retain all financial and program service records and all other records related to the Services and performance of this Agreement for at least three (3) years after expiration, termination or final payment under this Agreement, whichever occurs later. City's rights under this Section 15.0 shall survive for three (3) years after expiration, termination or final payment under this Agreement, whichever occurs later. 16.0 Safety Requirements All work performed under this Agreement shall be performed in such a manner as to provide safety to the public and to meet or exceed the safety standards outlined by CAL OSHA and other applicable state and federal laws. City may issue restraint or cease and desist orders to Contractor when unsafe or harmful acts are observed or reported relative to the performance of the Services. Contractor shall maintain the work sites free of hazards to persons and property resulting from its operations. Contractor shall immediately report to the City any hazardous condition noted by Contractor. 17.0 Insurance 17.1. General Requirements. Contractor shall not commence work under this Agreement until it has provided evidence satisfactory to the City that Contractor has secured all insurance required under this Section. 17.2. Minimum Scope and Limits of Insurance. Contractor shall, at its sole cost and expense, procure, maintain and keep in full force and effect for the duration of the Agreement, insurance against claims for injuries to persons or damages to property that may arise from or in connection with the performance of this Agreement, as follows: 10 of 19 17.2.1. Commercial General Liability Insurance: Contractor shall maintain limits no less than $2,000,000 per occurrence for bodily injury, personal injury and property damage; and if Commercial General Liability Insurance or other form with a general aggregate limit is used, either the general aggregate limit shall apply separately to this Agreement/location or the general aggregate limit shall be twice the required occurrence limit: Coverage shall be at least as broad as the latest version of Insurance Services Office Commercial General Liability coverage (occurrence form CG 0001). If Contractor is a limited liability company, the commercial general liability coverage shall be amended so that Contractor and its managers, affiliates, employees, agents and other persons necessary or incidental to its operation are insureds; 17.2.2. Automobile Liability Insurance: Contractor shall maintain limits no less than $1,000,000 per accident for bodily injury and property damage. Coverage shall be at least as broad as Automobile Liability: Insurance Services Office Business Auto Coverage form number CA 0001, code 1 (any auto).. 17.2.3. Workers' Compensation Insurance in the amount required by law; and Employer's Liability: $1,000,000 per accident and in the aggregate for bodily injury or disease; 17.3. Acceptability of Insurers. The Insurance policies required under this Section shall be placed with insurers with a current A.M. Best's rating no less than A:VIII, licensed to do business in California, and satisfactory to the City. 17.4. Additional Insured. 17.4.1. For general liability insurance, City, its elected and appointed officials, officers, employees, agents, designated volunteers and those City agents acting as independent contractors in the role of City officials shall be covered as additional insureds with respect to the services or operations performed by or on behalf of the Contractor, including materials, parts or equipment furnished in connection with such work. 17.4.2. For automobile liability insurance, City, its elected and appointed officials, officers, employees, agents, designated volunteers and those City agents serving as independent contractors in the role of City officials, shall be covered as additional insureds with respect to the ownership, operation, maintenance, use, loading or unloading of any auto owned, leased, hired or borrowed by the Contractor or for which the Contractor is responsible. 17.4.3. These additional insured provisions shall also apply to any excess/umbrella liability policies. 11 of 19 17.5. Cancellations or Modifications to Coverage. The insurance policies shall contain the following provisions, or Contractor shall provide endorsements on forms supplied or approved by City to state: (1) coverage shall not be suspended, voided, reduced or canceled except after 30 days prior written notice by certified mail, return receipt requested, has been given to City; (2) any failure to comply with reporting or other provisions of the policies, including breaches of warranties, shall not affect coverage provided to City, its elected and appointed officials, officers, employees, agents, designated volunteers, and those City agents serving as independent contractors in the role of City officials; 17.6. Primary and Non -Contributing. Coverage shall be primary insurance as respects the City, its elected officials, officers, employees, agents, designated volunteers designated volunteers and agents serving as independent contractors in the role of City officials, or if excess, shall stand in an unbroken chain of coverage excess of the Contractor's scheduled underlying coverage and that any insurance or self-insurance maintained by the City, its elected officials, officers, employees, agents. designated volunteers designated volunteers and agents serving as independent contractors in the role of City officials, shall be excess of the Contractor's insurance and shall not be called upon to contribute with it; 17.7. Separation of Insureds. All insurance required by this Section shall contain standard separation of insureds provisions and shall not contain any special limitations on the scope of protection afforded to City, its elected and appointed officials, officers, employees, agents, designated volunteers and those City agents serving as independent contractors in the role of City officials. 17.8. Deductibles and Self -Insured Retentions. Any deductibles or self- insured retentions shall be declared to and approved by City. Contractor guarantees that, at the option of City, either: (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions as respects City, its elected and appointed officials, officers, employees, agents, designated volunteers and those City agents serving as independent contractors in the role of City officials; or (2) Contractor shall procure a bond guaranteeing payment of losses and related investigation costs, claims and administrative and defense expenses. 17.9. Waiver of Subrogation. Each insurance policy required by this Agreement shall expressly waive the insurer's right of subrogation against City and its elected and appointed officials, officers, employees, agents, designated volunteers and those City agents serving as independent contractors in the role of City officials. Contractor hereby waives all rights of subrogation against City. 17.10. City Remedy for Noncompliance. If Contractor does not maintain the policies of insurance required under this Section in full force and effect during the term of this Agreement, or in the event any of Contractor's policies do not 12 of 19 comply with the requirements under this Section, City may either immediately terminate this Agreement or, if insurance is available at a reasonable cost, City may, but has no duty to, take out the necessary insurance and pay, at Contractor's expense, the premium thereon. Contractor shall promptly reimburse City for any premium paid by City or City may withhold amounts sufficient to pay the premiums from payments due to Contractor. 17.11. Evidence of Insurance. Prior to the performance of Services under this Agreement, Contractor shall furnish City with original certificates of insurance and all original endorsements evidencing and effecting the coverages required under this Section on forms satisfactory to and approved by City. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf, and shall be on forms provided by City if requested. Contractor may provide complete, certified copies of all required insurance policies to City. Contractor shall maintain current endorsements on file with City's Risk Manager. All certificates and endorsements shall be received and approved by the City before work commences. City reserves the right to require complete, certified copies of all required insurance policies, at any time. Contractor shall also provide proof to City that insurance policies expiring during the term of this Agreement have been renewed or replaced with other policies providing at least the same coverage. Contractor shall furnish such proof at least two weeks prior to the expiration of the coverages. 17.12. Indemnity Requirements Not Limiting. Procurement of insurance by Contractor shall not be construed as a limitation of Contractor's liability or as full performance of Contractor's duty to indemnify City under Section 18.0. 17.13. Broader Coverage/Higher Limits. If Contractor maintains broader coverage and/or higher limits than the minimums required above, City requires and shall be entitled to the broader coverage and/or the higher limits maintained by Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to City. 17.14. Subcontractor Insurance Requirements. Contractor shall require each of its subcontractors that perform Services under this Agreement to maintain insurance coverage that meets all of the requirements of this Section. 18.0 Indemnification, Hold Harmless, and Duty to Defend 18.1. Contractor's Duty. 18.1.1. To the fullest extent permitted by law, Contractor shall, at its sole cost and expense, protect, defend, hold harmless and indemnify City and its elected and appointed officials, officers, attorneys, agents, employees, designated volunteers, successors, assigns and those City agents serving as 13 of 191 independent contractors in the role of City officials (collectively "Indemnitees" in this Section 18.0), from and against any and all damages, costs, expenses, liabilities, claims, demands, causes of action, proceedings, judgments, penalties, bid protests, stop notices, liens and losses or injury of any nature whatsoever, in law or equity, to persons or property, including bodily injury, death, personal injury, property damage, including but not limited to fees of accountants, attorneys and other professionals, and all costs associated therewith, and the payment of all consequential damages (collectively "Liabilities"), whether actual, alleged or threatened, which arise out of, pertain to, or relate to any breach of this Agreement and/or the acts or omissions of Contractor, its officers, agents, servants, employees, subcontractors, materialmen, suppliers, or contractors, or their officers, agents, servants or employees (or any entity or individual that Contractor shall bear the legal liability thereof) in the performance of this Agreement, including the Indemnitees' active or passive negligence, except for Liabilities arising from the sole negligence or willful misconduct of the Indemnitees, as determined by final arbitration or court decision or by the agreement of the Parties. Contractor shall defend the Indemnitees in any action or actions filed in connection with any Liabilities with counsel of the Indemnitees' choice, and shall pay all costs and expenses, including all attorneys' fees and experts' costs actually incurred in connection with such defense. Contractor shall reimburse the Indemnitees for any and all legal expenses and costs incurred by the Indemnitees in connection therewith. 18.1.2. Contractor shall indemnify and hold harmless City in accordance with Sections 9.0 and 10.0. 18.2. Subcontractor Indemnification. Contractor shall obtain executed indemnity agreements with provisions identical to those in this Section 18.0 from each and every subcontractor or any other person or entity involved by, for, with or on behalf of Contractor in the performance of this Agreement. If Contractor fails to obtain such indemnities, Contractor shall be fully responsible and indemnify, hold harmless and defend the Indemnitees from and against any and all Claims in law or equity, whether actual, alleged or threatened, which arise out of, are claimed to arise out of, pertain to, or relate to the acts or omissions of Contractor's subcontractor, its officers, agents, servants, employees, subcontractors, materialmen, contractors or their officers, agents, servants or employees (or any entity or individual that Contractor's subcontractor shall bear the legal liability thereof) in the performance of this Agreement, including the Indemnitees' active or passive negligence, except for Liabilities arising from the sole negligence or willful misconduct of the Indemnitees, as determined by final arbitration or court decision or by the agreement of the Parties. 18.3. Workers' Compensation Acts Not Limiting. Contractor's indemnification obligations under this Section, or any other provision of this Agreement, shall not be limited by the provisions of any workers' compensation act or similar act. Contractor expressly waives its statutory immunity under such 14 of 19 statutes or laws as to City, its elected and appointed officers, officials, agents, employees, designated volunteers and those City agents serving as independent contractors in the role of City officials. 18.4. Insurance Requirements Not Limiting. City does not, and shall not, waive any rights that it may possess against Contractor because of the acceptance by City, or the deposit with City, of any insurance policy or certificate required pursuant to this Agreement. The indemnities and obligations in this Section shall apply regardless of whether or not any insurance policies are determined to be applicable to the Claims or Liabilities asserted against City or any of the other Indemnitees. 18.5. Survival of Terms. Contractor's indemnifications and obligations under this Section 18.0 shall survive the expiration or termination of this Agreement. 19.0 Non -Discrimination Equal Employment Opportunity Contractor affirmatively represents that it is an equal opportunity employer. In the performance of this Agreement, Contractor shall not discriminate against any subcontractor, employee, or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex, gender, sexual orientation, gender identity, gender expression, marital status, national origin, ancestry, age, physical disability, mental disability, medical condition, genetic information, or any other basis prohibited by law. Contractor will take affirmative action to ensure that subcontractors and applicants are employed, and that employees are treated during employment, without regard to their race, color, religious creed, sex, gender, gender identity, gender expression, marital status, national origin, ancestry, age, physical disability, mental disability, medical condition, genetic information or sexual orientation, or any other basis prohibited by law. 20.0 Labor Certification By its signature hereunder, Contractor certifies that it is aware of the provisions of Section 3700 of the California Labor Code that require every employer to be insured against liability for Workers' Compensation or to undertake self-insurance in accordance with the provisions of that Code, and agrees to comply with such provisions before commencing the performance of the Services. 21.0 Prevailing Wage and Payroll Records To the extent that this Agreement calls for services that, in whole or in part, constitute "public works" as defined in the California Labor Code, Contractor shall comply in all respects with all applicable provisions of the California Labor Code, including those set forth in Exhibit C, attached hereto and incorporated by reference herein. 15 of 19 22.0 Entire Agreement This Agreement contains the entire agreement of the Parties with respect to the subject matter hereof, and supersedes all prior negotiations, understandings, or agreements. This Agreement may only be modified by a writing signed by both Parties. 23.0 Severability The invalidity in whole or in part of any provisions of this Agreement shall not void or affect the validity of the other provisions of this Agreement. 24.0 Governing Law and Venue This Agreement shall be governed by and construed in accordance with the laws of the State of California, except that any rule of construction to the effect that ambiguities are to be resolved against the drafting party shall not be applied in interpreting this Agreement. Any dispute that arises under or relates to this Agreement (whether contract, tort or both) shall be resolved in a superior court with geographic jurisdiction over the City of Seal Beach. 25.0 No Third Party Beneficiaries This Agreement is made solely for the benefit of the Parties to this Agreement and their respective successors and assigns, and no other person or entity shall be deemed to have any rights hereunder against either party by virtue of this Agreement. 26.0 Waiver No delay or omission to exercise any right, power or remedy accruing to City under this Agreement shall impair any right, power or remedy of City, nor shall it be construed as a waiver of, or consent to, any breach or default. No waiver of any breach, any failure of a condition, or any right or remedy under this Agreement shall be (1) effective unless it is in writing and signed by the Party making the waiver, (2) deemed to be a waiver of, or consent to, any other breach, failure of a condition, or right or remedy, or (3) deemed to constitute a continuing waiver unless the writing expressly so states. 27.0 Prohibited Interests; Conflict of Interest 27.1. Contractor covenants that it presently has no interest and shall not acquire any interest, direct or indirect, which may be affected by the Services, or which would conflict in any manner with the performance of the Services. Contractor further covenants that, in performance of this Agreement, no person having any such interest shall be employed by it. Furthermore, Contractor shall 16 of 19 avoid the appearance of having any interest, which would conflict in any manner with the performance of the Services. Contractor shall not accept any employment or representation during the term of this Agreement which is or may likely make Contractor "financially interested" (as provided in California Government Code §§ 1090 and 87100) in any decision made by City on any matter in connection with which Contractor has been retained. 27.2. Contractor further warrants and maintains that it has not employed or retained any person or entity, other than a bona fide employee working exclusively for Contractor, to solicit or obtain this Agreement. Nor has Contractor paid or agreed to pay any person or entity, other than a bona fide employee working exclusively for Contractor, any fee, commission, gift, percentage, or any other consideration contingent upon the execution of this Agreement. Upon any breach or violation of this warranty, City shall have the right, at its sole and absolute discretion, to terminate this Agreement without further liability, or to deduct from any sums payable to Contractor hereunder the full amount or value of any such fee, commission, percentage or gift. 27.3. Contractor warrants and maintains that it has no knowledge that any officer or employee of City has any interest, whether contractual, non - contractual, financial, proprietary, or otherwise, in this transaction or in the business of Contractor, and that if any such interest comes to the knowledge of Contractor at any time during the term of this Agreement, Contractor shall immediately make a complete, written disclosure of such interest to City, even if such interest would not be deemed a prohibited "conflict of interest" under applicable laws as described in this Section. 28.0 Final Payment Acceptance Constitutes Release The acceptance by Contractor of the final payment made under this Agreement shall operate as and be a release of City from all claims and liabilities for compensation to Contractor for anything done, furnished or relating to Contractor's work or services. Acceptance of payment shall be any negotiation of City's check or the failure to make a written extra compensation claim within ten calendar days of the receipt of that check. However, approval or payment by City shall not constitute, nor be deemed, a release of the responsibility and liability of Contractor, its employees, subcontractors and agents for the accuracy and competency of the information provided and/or work performed; nor shall such approval or payment be deemed to be an assumption of such responsibility or liability by City for any defect or error in the work prepared by Contractor, its employees, subcontractors and agents. 29.0 Corrections In addition to the indemnification obligations set forth above, Contractor shall correct, at its expense, all errors in the work which may be disclosed during City's review of Contractor's report or plans. Should Contractor fail to make such 17 of 19 correction in a reasonably timely manner, such correction may be made by City, and the cost thereof shall be charged to Contractor. In addition to all other available remedies, City may deduct the cost of such correction from any retention amount held by City or may withhold payment otherwise owed Contractor under this Agreement up to the amount of the cost of correction. 30.0 Non -Appropriation of Funds i Payments to be made to Contractor by City for any Services performed within the current fiscal year are within the current fiscal budget and within an available, unexhausted fund. In the event that City does not appropriate sufficient funds for payment of Contractor's Services beyond the current fiscal year, this Agreement - shall cover payment for Contractor's Services only to the conclusion of the last fiscal year in which City appropriates sufficient funds and shall automatically terminate at the conclusion of such fiscal year. 31.0 Mutual Cooperation 31.1. City's Cooperation. City shall provide Contractor with all pertinent Data, documents and other requested information as is reasonably available for Contractor's proper performance of the Services required under this Agreement. 31.2. Contractor's Cooperation. In the event any claim or action is brought against City relating to Contractor's performance of Services rendered under this Agreement, Contractor shall render any reasonable assistance that City requires. 32.0 Time of the Essence Time is of the essence in respect to all provisions of this Agreement that specify a time for performance; provided, however, that the foregoing shall not be construed to limit or deprive a Party of the benefits of any grace or use period allowed in this Agreement. 33.0 Attorneys' Fees If either party commences an action against the other party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing party in such litigation shall be entitled to have and recover from the losing party all of its attorneys' fees and other costs incurred in connection therewith. 34.0 Exhibits All exhibits referenced in this Agreement are hereby incorporated into the Agreement as if set forth in full herein. In the event of any material discrepancy 18 of 19 between the terms of any exhibit so incorporated and the terms of this Agreement, the terms of this Agreement shall control. 35.0 Corporate Authority The person executing this Agreement on behalf of Contractor warrants that he or she is duly authorized to execute this Agreement on behalf of said party and that by his or her execution, the Contractor is formally bound to the provisions of this Agreement. IN WITNESS WHEREOF, the Parties hereto, through their respective authorized representatives have executed this Agreement as of the date and year first above written. CITY OF SEAL BEACH 2 Attest: Approved as to For By: A- raig A. Steele, City Attorney CONTRACTOR: LEED Electric, Inc., a California corporation By: Name: Its: Seyed A. Jamali Dinan Chief Exec Live Officer Rodney Dean Vice -President (Please note, two signatures required for corporations pursuant to California Corporations Code Section 393 from each of the following categories. (i) the chairperson of the board, the president or any vice president, and (ii) the secretary, any assistant secretary, the chief financial officer or any assistant treasurer of such corporation.) 19 of 19 EXHIBIT A Request for Proposals for On -Call Electrical Maintenance and Repair Services City of Seal Beach Request for Proposals for On -Call Electrical Maintenance and Repair Services RFP responses to be received until 2:00 P.M., October 8, 2021 in the Public Works Department ATfN: Iris Lee, City Engineer/Deputy Public Works Director Approved for Advertising: Iris Lee City Engineer Date Issued: September 15, 2021 r Table of Contents INTRODUCTION II. QUALIFICATIONS III. SCOPE OF SERVICES IV. PRE -PROPOSAL QUESTIONS V. SCHEDULE VI. SUBMITTAL REQUIREMENTS VII. FEE & COST PROPOSAL VIII. INTERVIEW IX. SELECTION PROCESS X. SPECIAL PROVISIONS XI. GENERAL CONDITIONS EXHIBIT A — Fee & Cost Proposal EXHIBIT B — Sample Contract xhibit samples removed as part of final agreement. 2 % c C ,C f /• (i� iG�G�GI C (i./Tl NCI�Cr' ! . REQUEST FOR PROPOSALS FOR ON-CALL ELECTRICAL MAINTENANCE AND REPAIR SERVICES ALL INTERESTED PARTIES MUST REGISTER BY EMAILING ilee@,sealbeaclica.gov. COMMUNICATION AND ADDENDA, IF ANY, WILL BE DISTRIBUTED TO REGISTERED PARTIES VIA EMAIL PROVIDED. INTRODUCTION The City of Seal Beach ("City") owns and operates municipal facilities and utility infrastructure that are powered by electricity and equipped with motor systems. The City is seeking one or more well-qualified contractors who would be available to provide on-call electrical maintenance and repair services in both emergency and unplanned situations, for an anticipated term of three 3 ears. The Contractor shall furnish all necessary materials, labor, equipment and other incidental and appurtenant work necessary as identified in the scope of work. The final agreement amount and term will depend on the quality, diversity, responsiveness of the received proposals, and the future need for emergency and unexpected task work. The scope, work schedule, and fee for repair services will be negotiated on a task -by -task basis. The City reserves the right to not accept the Contractor's scope and fee. Due to the on-call nature of this contract, no work is guaranteed, even if awarded. QUALIFICATIONS Minimum Qualifications • Valid California Contractor's Class C10 -Electrical license issued by the Department of Consumer Affairs — Contractors State License Board by the time of proposal submittal and shall remain valid for the term of the Agreement. • Valid City of Seal Beach business license for the term of the Agreement, if selected. • Minimum ten (10) years of professional electrical maintenance and repair service. • Ability to mobilize and respond to emergency job sites, as necessary within the time frames provided in this RFP. • Maintain, or have the ability to quickly acquire, all necessary labor, equipment, and material to promptly complete the Work. 3 • Registered with the Department of Industrial Relations. Desirable Qualifications • Knowledge and experience with the City of Seal Beach's standards, provisions, and practices. • Familiarity with public sector maintenance and repair contracts. • Adequate availability of key team members. SCOPE OF SERVICES Work to be done consists of furnishing all labor, supervision, methods of processes, implements, tools, machinery, safety equipment, traffic control, materials and proper licensing required to identify, list, and perform electrical maintenance and repair services in those areas designated by the City on an emergency or unexpected task basis. Due to the on-call/as-needed nature of this Agreement, Work may vary according to the need and there is no guarantee that work will be assigned. The work may include, but is not limited to, complete troubleshooting/evaluating, laying out, installing, repairing, routing/rerouting, replacing, wiring, testing, and inspecting electrical services, electrical wire systems, and components used to provide heat, light, power, air conditioning, refrigeration, pumps, motors in municipal buildings, facilities, and utilities. Services may also include installing and repairing conduits and other materials; connecting electrical machinery equipment, controls, and transmission systems and service other electrical related issues that may arise and services necessary to ensure safe, well maintained electrical systems. Work shall comply with the National Electrical Code, California Mechanical Code, Standard Specifications for Public Works Construction (latest edition, unless otherwise noted), City of Seal Beach standards and provisions, Caltrans Standard Specifications, and any related codes, specifications, standards, policies, and regulations from Agencies Having Jurisdiction (AHJ's). Repair Work Repair Work will require a written cost proposal from the contractor and approval from the City prior to commencing work. Work shall be charged according to the Fee and Cost Proposal. The cost incurred for any materials and parts used by the contractor shall be billed to the City with up to a 15% mark-up. Invoices submitted to the City for payment must include back-up documentation indicating the price charged to the contractor for materials. The hourly rate charged to the City shall be for time spent on the job — driving to and from the job site is not included in that cost. Prior to payment of invoices, contractor must furnish preventative maintenance checklists for each location serviced that clearly identifies the work completed at each site. No additional compensation will be allowed for extraordinary repairs. 4 IV. PRE -PROPOSAL QUESTIONS For answers to questions or particulars regarding this Request for Proposal, all interested parties are to contact: Iris Lee City Engineer/Deputy Public Works Director Department of Public Works 211 Eighth Street Seal Beach, CA 90740 ileeCa.sealbeachca.gov (562) 431-2527 ext. 1322 The City will respond to all questions and requests for clarification received by October 1, 2021. V. SCHEDULE The following dates reflect the anticipated schedule: ■ Request for Proposal Solicitation 9/15/2021 ■ Pre -Proposal Question Deadline 10/1/2021 ■ Proposal Submittal Deadline 10/8/2021, 2:00p.m. ■ Contractor Interview (if conducted) October 2021 ■ Contract Award by City Council November 2021 ■ Notice to Proceed December 2021 VI. SUBMITTAL REQUIREMENTS Acceptance of Submittals Proposals are due by 2:00 PM on October 8, 2021 to the following. Postmarks will not be accepted. Iris Lee City Engineer/Deputy Public Works Director City of Seal Beach 211 Eighth Street Seal Beach, CA 90740 ilee(cD-sealbeachca.gov (562) 431-2527 ext. 1322 Please submit three (3) bound hard copies, and one (1) electronic copy of the Contractor's Proposal. Proposals received after the date and time listed above will not be accepted or considered for this Project. There is no expressed or implied obligation for City to reimburse firms for any expenses incurred in preparing proposals in response to this request. Materials submitted by respondents are subject to public inspection under the California Public Records Act (Government Code Sec. 6250 et seq.). Any language purporting to render the entire proposal confidential or propriety will be ineffective and will be disregarded. The City reserves the right to retain all proposals submitted, and to use any idea in a proposal regardless of whether the proposal was selected. Submission of a proposal indicates acceptance by the firm of the conditions contained in the RFP, unless clearly and specifically noted in the proposal submitted and confirmed in the contract between the City and the selected Contractor. All property rights, including publication rights of all reports produced by the selected Contractor in connection with services performed under this Agreement shall be vested in the City. Information to be Submitted The following information shall be provided, at a minimum: Cover Letter Table of Contents Company Qualifications Local Staffing List Understanding/Approach References List of Subcontractors Sample Letter Proposal Cost Proposal Exceptions Business Entity DIR Registration Number/Contractor's License Contract Signatories Cover Letter: Cover letter shall not exceed two pages. It shall provide an executive summary of the proposal, and designate the firm's authorized representative regarding this RFP. Table of Contents: The table of contents shall list the following sections with page numbers and information in each section shall be provided. Company Qualifications: Provide a summary of the Contractor's qualifications, including background and experience. Local Staffing List: Provide an organizational chart showing the names, positions, responsibilities, and availability of the individual(s) that would be assigned to this Agreement, including sub -Contractors. Identify the individual(s) authorized to negotiate the contract on behalf of the Contractor's firm and the Contractor's project manager. Understanding/Approach: Describe the Contractor's understanding of the Work requested in this RFP, any key issues that may need special attention. Describe how the Contractor will approach the scope of services and each task needed to complete the project. Any task assumptions and/or exclusions shall be clearly identified. References: Contractor should provide a minimum of five (5) references from public agencies the Contractor has performed work for within the last five (5) years. Information shall include, at a minimum: • Agency name • Scope of work and/or services provided, prime/sub-Contractor. i • Project outcome • Construction and/or contract value • Dates • Client project manager name, valid telephone number, and email List of Subcontractors: Contractor will be required to provide a list of subcontractors that it intends to use. Contractor's license and class, DIR registration, address, phone number, and type of work shall be provided for each subcontractor, at a minimum. Subcontractor must comply with all applicable licensing requirements. Sample Letter Proposal: Contractor will be required to submit a sample letter proposal providing a template of how the Contractor intends to respond to each Work request. Fee & Cost Proposal: Contractors will be required to submit a "Fee & Cost Proposal for On -Call Electrical Maintenance and Repair Services" as shown in Exhibit A. Additional labor/material rates may be provided in addition to Exhibit A. All rates shall remain for the term of the contract as permitted by law, unless specifically detailed as a supplement to Exhibit A. Exceptions: The Contractor shall review this RFP and attached sample contract. Exceptions to any portion of the RFP and/or City's standard agreement will need to be clearly identified. Identification of exceptions does not constitute City concurrence and acceptance. Exceptions may be negotiated with the top-ranked firm. Business Entity: Clearly indicate the firm's business entity type (i.e., a California corporation). DIR Registration/Contractor's License: Clearly indicate the Contractor's Department of Industrial Relations registration number for the prime/sub-Contractor, and provide the Contractor and sub -Contractor's license information. Contract Signatories: Provide the two binding signatories for the firm, pursuant to California Corporation Code Section 313. VII. FEE & COST PROPOSAL In preparing the Fee & Cost Proposal for this project, the Contractor shall take into consideration the following: 1. Unless specially noted, compensation for any services provided will be on a time -and -materials. 2. Fee and cost proposal, and billing rates shall remain effective for the term of the Agreement. Any anticipated billing/rate adjustments shall be clearly identified in the Proposal. 3. The Contractor's standard, overtime, and double-timing, billing rates for all classifications of staff likely to be involved shall be included with the fee proposal along with the mark-up rate for any non -labor expenses and sub -Contractors. Any anticipated fee adjustments shall be clearly noted. 4. The City will negotiate the final fee with the top-ranking Contractor(s), if necessary. 7 VIII. INTERVIEW Top ranked Contractor team(s) may be interviewed by the selection committee. Proposed key personnel from the Contractor's team may be requested to present the teams' and their qualifications at an interview. IX. SELECTION PROCESS Proposals will be evaluated on the basis of the response to all provisions of this RFP. Since this solicitation is an RFP as opposed to a Bid, pricing alone will not constitute the entire selection criteria. The City may use some or all of the following criterion in its evaluation and comparison of proposals submitted. The criteria listed are not necessarily an all-inclusive list. The order in which they appear is not intended to indicate their relative importance. The City reserves the right to modify the evaluation criterion and percentage of score as deemed appropriate prior to the commencement of evaluation. The City reserves the right to determine whether or not a proposal meets the specifications and requirements of this RFP and reject any proposal that, in the City's sole opinion, fails to meet the detail or intent of the requirements. The City reserves the right to reject any and all proposals. POTENTIAL EVALUATION CRITERIA 1. Completeness of Response (Pass/Fail) Responses to this RFP must be complete. Responses that do not include the proposal content requirements identified within this RFP and subsequent addenda and do not address each of the requested items will be considered incomplete, may be rated a Fail in the Evaluation Criteria, and may receive no further consideration. 2. Qualifications & Experience (35 points) a. Local Presence - A statement addressing firm's ability to effectively conduct the Work for the City based on the Firm's location. b. Relevant experience, specific qualifications, and technical expertise of the Contractor and sub -Contractors to perform the work. c. Provide as reference the name of at least five (5) agencies the Contractor currently or have previously consulted for in the past five (5) years. 3. Organization & Approach (30 points) a. Contractor's understanding of requested Work b. Contractor's ability to deploy the appropriate resources to promptly meet requested emergency and/or non -emergency Work. c. Contractor's availability to complete both small and large scale services without the compromise of quality, cost, and/or time. d. Contractor's ability to self -perform the requested Work, or form a quality sub -contracting team. e. Contractor's understanding of the nature of public sector work and its decision-making r process. f. Contractor's proposal conforming to the Request for Proposals and Professional Maintenance Agreement. 4. Fee. (35 points) a. Fee & Cost proposal b. Quality of sample letter proposal The City reserves the right to determine whether or not a proposal meets the specifications and requirements of this RFP and reject any proposal that, in the City's sole opinion, fails to meet the detail or intent of the requirements. The City reserves the right to reject any and all proposals. All proposals received as specified will be evaluated by City staff in accordance with the abovementioned. During the evaluation period, the City may do any or all of the following: generate a "short list" and conduct interviews with the top candidates; conduct on-site visits and/or tours of the candidates' places of business. Contractors should be aware that award may be made without Contractor visits, interviews, or further discussion or negotiations. X. SPECIAL PROVISIONS a. Normal working hours will generally be between the hours of 7:30 AM and 5:30 PM, Monday through Friday. During emergencies, work may be required at other than normal hours. The Contractor must receive the approval of the City prior to commencing Work during hours outside those stated above. b. Contractor shall maintain an adequate crew of at least two experienced employees to perform the services required. c. Contractor will be required to supply a list of equipment owned and available for Work. d. Contractor will be required to supply a list of references for similar work performed. e. Contractor will be required to include a list of sub -contractors with the Proposal, if applicable. A form for this purpose is found herein. f. Contractor will be required to supply additional experience references, if requested. g. Contractor shall provide City with required proof of liability insurance, workman's compensation insurance, vehicle insurance, and City business license as noted in the contract. h. Contractor shall be responsible for Contractor's compliance in all respects with the prevailing wage rates to all the laborers involved, and with California Labor Code Section 1770 et seq., including the keeping of all records required by the provisions of Labor Code Section 1776 and the implementing administrative regulations. The City shall be a third party beneficiary of the forgoing covenant with rights to enforce the same as against the Contractor. i. Hourly rates and unit prices quoted shall include all safety equipment required. Traffic control may be 0 ~�f 1�✓p�l �i� WTI required on some sites, and shall be included in quoted prices. j. Hourly rates for emergency work shall be for actual time spent on the job site. No travel time will be paid. k. At any time prior to proposal due date, Contractor may inspect City property for further information, if desired. City representatives will be available if desired to answer questions. PERSONNEL The Contractor shall use and furnish all labor necessary for the satisfactory performance for the Work set forth in this Agreement. a. Contractor's Staff The Contractor shall require each of his/her employees to adhere to basic standards of working attire and other gear required by State Safety Regulations, and proper wearing of clothing. b. Typical Tasks Contractor shall supply staff with the necessary skills to perform duties in connection with electrical maintenance and repair services. c. Licenses Contractor shall possess a valid Contractor's "C-10" License issued by the Department of Consumer Affairs — Contractors State License Board by the time of proposal submittal and shall remain valid for the term of the Agreement. Contractor shall have a valid City of Seal Beach business license for the term of the Agreement, if selected. d. Knowledge and Abilities The Contractor's representative shall have a general knowledge of the electrical maintenance and repair industry, including suitable experience in the field to perform the required work in a safe and thoughtful manner EQUIPMENT The contractor shall use and furnish all equipment necessary for the satisfactory performance of the Work set forth in this Agreement. a. Vehicle and Equipment Maintenance All vehicles and equipment used by the Contractor shall be maintained in a good operable mechanical condition. All equipment shall be properly adjusted, from an operational safety standpoint. b. Storage of Equipment 10 The Contractor is required to supply storage for equipment that is used in the City. Equipment shall not be stored in the public right-of-way or on any City property without written authorization from the City. SUPERVISION The Contractor shall provide such adequate supervision as to furnish ongoing supervision of workmanship and adherence to schedules by the staff performing the Work. The Contractor shall submit such reports as the City may require ensuring compliance with scheduled Work. Foremen shall have a minimum of five (5) years of experience in the utility maintenance and repair field. METHOD OF WORK The electrical maintenance and repair work shall involve all work necessary to complete the work in place. The Contractor shall ensure all work performed under this contract be in such a manner as to provide maximum safety to the public and their staff. Where applicable, Contractor must comply with all safety standards required by all regulatory agencies including but not limited to: California Division of Occupational Safety and Health (CAL -OSHA), South Coast Air Quality Management District (SCAQMD), and the Orange County Environmental Health Care Agency (OCEHC). This also includes local regulatory compliance set,forth by the City of Seal Beach, applicable Building Codes, Equipment Manufactures specifications, and other governing bodies or Agencies Having Jurisdiction (AHJ's). The City reserves the right to issue restraint, or cease and desist orders to the Contractor when unsafe or harmful acts are observed or reported relative to the performance under this contract. The Contractor shall be responsible and shall take necessary precautions to protect work sites free of hazards and/or damages, until the Work is accepted by the City. Any hazardous conditions noted by the Contractor, which is not a result of his/her operations, shall be immediately reported to the City. Rubbish and construction debris shall be promptly removed from the work area and properly disposed of to an approved disposal site. After removal operations have been completed, the grounds shall be left in a neat, safe, and presentable condition, to the satisfaction of the City. TRAFFIC CONTROL The Contractor shall maintain a safe environment at all times. Appropriate State/City traffic control standards and/or policies shall be adhered to for all Work. Any restrictions, due to the Work that cause travel ways to be less than State/City minimum requirement, shall have appropriate traffic control (in accordance with State specifications, policies, and procedures installed prior to the beginning of Work and remaining until all Work is completed to the satisfaction of the City. All traffic control, at a minimum, shall adhere to requirements of the Work Area Traffic Control Handbook (WATCH Manual). Payment for traffic control shall be included in the various items in the cost proposal. PROTECTION FROM DAMAGE The Contractor shall protect all public and private property that is not part of Work. Contractor shall protect property and facilities adjacent to and within the work areas. The work area shall be 11 safe, clean, and presentable condition, as determined by the City. All public or privately owned improvements and facilities shall be restored to their original condition and location, or better, using new material only. Contractor shall repair such damage at Contractor's sole expense. Nothing herein shall be construed to entitle the Contractor exclusive use of any public right-of-way or City property. Contractor shall conduct his/her operations so as not to interfere with the authorized work of utility companies or other agencies. PROTECTION OF EXISTING UTILITIES The Contractor must take all due precautionary measures to protect all of the existing utilities. When necessary, the Contractor shall have all utilities located by contacting the responsible agency at least 48 hours prior to commencing any work. The Contractor's attention is directed to the one -call utility notification service provided by Underground Service Alert (USA). USA member utilities will provide the Contractor with the locations of their substructures when given at least 48 hour notice. Such requests should be requested through USA (1-800-422-4133). TELEPHONE ELECTRONIC MAIL AND EMERGENCY SERVICE CONTACT INFORMATION The Contractor shall provide the City at all times throughout the duration of this contract emergency telephone numbers of at least two (2) qualified persons who can be called for emergency conditions at any time that Contractor's representatives are not immediately available at the job site. An alternate emergency number shall be provided in case no answer is received at the first number. The emergency number shall be used to contact the Contractor representative who can take the necessary action required to alleviate an emergency condition. In addition, the Contractor shall employ person(s) to answer telephone and e-mail complaints, requests for service, etc. (an answering service will not be considered sufficient for this purpose) during normal City business hours. Normal City business hours are 7:30 A.M. to 5:30 P.M., Monday through Friday. AUTHORIZATION OF WORK Unless otherwise noted as an emergency, City will coordinate with Contractor to schedule the work with a minimum seven (7) -day prior notification. In an emergency, Contractor shall respond and mobilize within three (3) hours after initial request from the City for Work under this contract. Contractor shall perform the on-call services described in the Section III - Scope of Services ("Services" or "Work"). Upon written request from the City, Contractor shall provide a "letter proposal" for Services requested by the City (hereinafter referred to as the "Letter Proposal"). At a minimum, the Letter Proposal shall include, but is not limited to, the following: • A detailed description of the Work to be provided; • The estimated number of hours, by task, and cost to complete the Work; and 12 • A detailed Work schedule. No Services shall be provided until the City has provided written acceptance of the Letter Proposal, unless in an emergency situation after Contractor has received a written notice to proceed from the City Engineer or designee. Once authorized to proceed, Contractor shall diligently perform the duties in the approved Letter Proposal or notice to proceed. PROGRESS OF WORK Time is of the essence on every aspect of the Work. Work shall proceed in an expeditious and orderly manner. The Contractor shall endeavor to avoid service interruptions to the extent feasible. Wherever possible, Work shall be completely finished prior to proceeding to the next location. Any exceptions shall be approved by the City. ALTERATIONS The City reserves the right to increase or decrease the quantity of any item or portion of the Work or to omit portions of the Work as may be deemed necessary or advisable by the City. The City may make such alterations or deviations, additions to, or omissions from these specifications, as may be determined during the progress of the work to be necessary and advisable for the proper completion thereof. Such alterations or deviations, additions or omissions shall in no way affect or make void the Agreement. Upon written order of the City, Contractor shall proceed with the Work as increased, decreased or altered. EXTRA WORK Extra work shall not be performed without prior written approval by the City unless public safety is immediately at risk. 2. Extra work may be required, and extra time may be granted, by the City as a result of acts of God, vandalism, theft, civil disturbances, accidents, or improvements. 3. If unit prices are not available, payment for extra work will be based on actual cost of labor, plus wholesale cost of materials, plus an industry standard markup not to exceed 15%. Extra services other than those listed in Exhibit A shall be negotiated on a time -and -material basis with a "not to exceed" amount. ACCEPTANCE OF WORK DONE The City, at its sole discretion, will make inspections and determine that the Work has been completed in all respects in accordance with the referenced specification, and if applicable, accepted. BILLING FORM, RECORDS, AND REPORTS The Contractor shall maintain a record of all work performed, including but not limited to location, types, and amounts maintained/installed/removed. These records shall list the date(s) of the Work performed. A copy of 13 iFWARIMPIRIA such record shall be provided to the City upon completion of each Task Order. Contractor shall maintain such record through the term of the Agreement, plus three (3) years after Contract termination. The Contractor shall return appropriate and completed Task Orders showing the date and inventory of work performed, signed by an authorized representative of Contractor and attached to each invoice. Contractor shall provide a billing form and progress payment form approved by the City. WITHHOLDING OF PAYMENT If, in the event that deficiencies are determined by City, the Contractor will have 24 hours from the time of notification to remedy said deficiency. If Contractor fails to correct within 24 hours, Contractor shall be fined the amount previously determined at the time of the initial inspection. Deductions from the monthly payment due for Work not performed will be based upon the cost worksheets, which are to be submitted at the time of submittal of the Letter Proposal plus mark-up. XI. GENERAL CONDITIONS A. Signature The Letter Proposal shall be signed by an individual authorized to bind the Contractor. B. Other Considerations: The City shall not be liable for any pre -contractual expenses incurred by any firm considering submitting a proposal in response to this RFP. The City reserves the right to accept or reject any and all proposals, or any part of, or waive any informalities or irregularities. The City reserves the right to withdraw, to cancel this RFP at any time without prior notice and the City makes no representations that any contract will be awarded to any firm responding this RFP. C. Business License Required The Seal Beach Municipal Code requires all businesses operating in the City to pay a business license tax. For more information, go to www.sealbeachca.gov. D. Prevailing Wage All work performed in connection with execution of this contract work shall be performed in compliance with all applicable laws, ordinances, rules and regulations of federal, state, county or municipal governments or agencies (including, without limitation, all applicable federal and state labor standards, including the prevailing wage provisions of sections 1770 et seq. of the California Labor Code), and (b) all directions, rules and regulations of any fire marshal, health officer, building inspector, or other officer of every governmental agency now having or hereafter acquiring jurisdiction. The Contractor shall indemnify, defend and hold the City harmless from any and all claims, causes of action and liabilities based upon or arising from the failure of any work related to the Agreement to comply with all such applicable legal requirements, including, without limitation, any such claims, causes of action or liabilities that may be asserted against or incurred by City with respect to or in any way arising from the Project's compliance with or failure to comply with applicable laws, including all applicable federal and 14 state labor requirements including, without limitation, the requirements of California Labor Code section 1770 et seq. Contractor agrees that all public work (as defined in California Labor Code section (1720) performed pursuant to this Agreement (the "Public Work"), if any, shall comply with the requirements of California Labor Code sections 1770 et seq. City makes no representation or statement that the project or any portion thereof, is or is not a "public work" as defined in California Labor Code section 1720. In all, bid specifications, contracts and subcontracts for any such Public Work, Contractor shall obtain the general prevailing rate of per diem wages and the general prevailing rate for holiday and overtime work in this locality for each craft, classification or type of worker needed to perform the Public Work, and shall include such rates in the bid specifications, contract or subcontract. Such bid specifications, contract or subcontract must contain the following provision: "It shall be mandatory for the Contractor to pay not less than the said prevailing rate of wages to all workers employed by the contractor in the execution of this contract. The Contractor expressly agrees to comply with the penalty provisions of California Labor Code section 1775 and the payroll record keeping requirements of California Labor Code section 1771." E. Registration with the Department of Industrial Relations In accordance with Labor Code Sections 1725.5 and 1771.1, no contractor or subcontractor shall be qualified to bid on, be listed in a proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, unless currently registered and qualified to perform public work pursuant to Section 1725.5. [with limited exceptions for bid purposes only under Labor Code Section 1771.1(a)]. The Department of Industrial Relations Registration Number shall be listed for the Contractor and each subcontractor, if any, in the proposal. 15 EXHIBIT B Contractor's Proposal 0 � 1===LJ ELECTRIC LIC. # 379096 C10,A Power, Control and Instrumentation Contractor Since 1979 MEMBER OF THE NATIONAL ELECTRICAL CONTRACTORS ASSOCIATION 13138 ARCTIC CIRCLE I SANTA FE SPRINGS I CA 90670 TEL: (562) 270-9500 FAX: (562) 863-5723 www.LEEDELECTRIC.com CITY OF SEAL BEACH REQUEST FOR PORPOSALS FOR ON-CALL ELECTRICAL MAINTENANCE AND REPAIR SERVICES October 7, 2021 ■ ��� ICCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications LEED Electric, Inc. is pleased to submit this executive summary as the electrical subcontractor for this request for proposal for the City of Seal Beach, On -Call Electrical Maintenance and Repair Services. LEED Electric has provided quality services through a long 42 year history with the County of Los Angeles, the City of Los Angeles, County of Orange, the Metropolitan Water District of Southern California, the Department of Water and Power, Long Beach Water Department, City of Santa Monica Water Resources Division and most recently the Water Replenishment District (WRD) of Southern California and Los Angeles Wastewater Information Network System (LAWINS). Leed Electric, Inc. is a qualified Small Business with the State of California Department of General Services as well as County of Los Angeles Office of Affirmative Action Compliance as an eligible participant in the County of Los Angeles Local Small Business Enterprise (LSBE) Preference Program. Numerous other public works projects have been successfully completed for virtually every local City and/or County governmental agency including Orange County Water District, Orange County Sanitation District, Los Angeles County Sanitation District, State of California Water Resources and other state agencies. LEI currently holds Electrical Maintenance Service contracts with the County of Los Angeles Seawater Barrier Telemetry Maintenance, Long Beach Water Department, WRD of Southern California, City of Santa Ana, City of Santa Monica, City of Montebello and Mesa Water Agency, we look forward to working with the City of Seal Beach. LEED Electric, Inc. employs local tradesmen affiliated with the International Brotherhood of Electrical Workers, and is signatory with IBEW locals from Ventura to San Diego County, and complies with Project Labor Agreements (PLA). Leed Electric has extensive experience in industrial water related projects and intricate electrical control projects in the greater Los Angeles, Orange County and Riverside County areas. LEI is dedicated to on-time delivery of materials, labor and services for construction endeavors at all times, and along with the on-time delivery LEI responds to all inquiries for service in a timely and professional manner, with a commitment to provide the products or services meeting or exceeding the specifications of the customer. LEED Electric, Inc. (LEI) is a local full service electrical contractor with extensive experience in public works projects, having successfully completed hundreds of public works contracts during their 42 - year history -from a high end of $7.OM to various projects in the $500K to $2.OM ranges. In addition to the minimum qualifications for participation in this Electrical Pre -Qualification, LEED Electric offers: • 42 -year history of excellent working relationship with public agencies throughout California • Southern California locally based operations, with an Orange County Office in Aliso Viejo and our Corporate Office Located in Santa Fe Springs, CA, with satellite offices in Huntington Beach, Santa Clarita and Riverside. • LEED Electric is registered with the DIR. • Corporation registered with the State of California • Experienced project managers and staff as relates to compliance with goal -oriented projects • Over 20 Administrative Staff • Over 60 IBEW Union Electricians • 24 Hour Phone Line (888) 609-0872 • Locally hired union workforce with vast manpower capabilities 11 C o v e r L e t t e r Leed Electric Inc. Oct. 8, 2021 ■ ®�� IMMMIJ ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications • LEED Electric is a Licensed A & C-10 General Contractor and Electrical Contractor with the State of California. • LEED Electric is certified by the County of Los Angeles Office of Affirmative Action Compliance as an eligible participant in the County of Los Angeles Local Small Business Enterprise Preference Program. • Fleet of over 30 pick up trucks with cross -top toolboxes containing power and hand tools. • Fleet of 2, 16FT F-550 Stake Beds, 4x4 F-550 Dually Diesel Service Truck, and 6 Ford F-350 Service Trucks In summary; our team! of local craftsmen overseen by an experienced management team that consists of a Chief Executive Officer, Operations Manager, General Superintendent, Contract Managers, Senior Project Managers, Project Managers, Project Engineers, Assistant Project Managers, Project Coordinators, and Administrative Professionals to oversee quality products and services are provided and has the requisite expertise and experience in working as the electrical subcontractor for the City of Seal Beach. Some of our satisfied customers are included in the latter portion of this RFP or can be requested. We hope you determine that our qualifications meet your requirements. Please contact me Seyed A. Jamali Dinan, at sjamali@leedelectric.com or (562) 270-9500 with any questions. Our Designated Authorized Representative, Seyed A. Jamali Dinan, Chief Executive Officer 2 1 C o v e r L e t t e r Leed Electric b:c. Oct. 8, 2021 IITable of Contents LEED Electric Inc. Oct. 8, 2021 City of Seal Beach En�.CCY RFP On -Call Electrical Maintenance and Repair Services ELECTRIC LEED Electric, Inc. — Statement of Qualifications Table of Contents Cover Letter Table of Contents 4 Section A Company Qualifications 5 Section B Local Staffing List 8 Section C Understanding/Approach 25 Section D References 27 Section E List of Subcontractors 41 Section F Sample Letter Proposal 42 Section G Cost Proposal 45 Section H Exceptions 49 Section I Business Entity 50 Section J DIR Registration Number/Contractor's License 56 Section K Contract Signatures 60 IITable of Contents LEED Electric Inc. Oct. 8, 2021 ■ ��� `CCU ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications BACKGROUND LEED Electric Inc. is an experienced and highly -recommended full-service commercial and industrial electrical, control & instrumentation contractor. The company has a reputation for completing projects on time, within budget and to the client's satisfaction. The company's comprehensive knowledge of new technologies combined with the highly trained staff and more than 42 years of experience performing heavy contracting work make LEED Electric a provider of choice. LEED Electric began operations in 1979 performing work at oil refineries, chemical plants and aerospace facilities. Later began doing public work for various municipal and county facilities on pumping plants, water treatment plants, and sewage treatment plants installing power and control systems, automation/measuring systems. MISSION The mission of LEED Electric is to provide highest quality electrical, control & instrumentation installations performed safely by highly trained, skilled craftsmen to meet or exceed customer specifications. VERSATILITY Contracts ranging to over $5.0 million have been successfully completed. Maintenance programs with special rates designed to fit customer needs have been provided. PERFORMANCE LEED Electric has a consistent record of completed projects on or before target dates. SAFETY Strict adherence to safety standards is an integral part of daily operations. COMMUNICATION LEED Electric's experienced management team is concerned about completing projects correctly and on time. The company understands that growing reputation depends on it. Constant communications with field personnel enables project managers to stay informed of job progress insuring smooth operation to timely completion. LITIGATION LEED Electric has not had any litigation or threatened litigation against the firm that will affect the company's performance or completion of this proposed program. a. The organization has never been subject of litigation for failure to meet contracted obligations to deliver or supply electricity since its inception in 1979. b. The company has no breach of contract or criminal legal actions with potential liabilities above $50,000 or involving imprisonment (now or pending) against the company itself, any official, officer or employee of the company submitting qualifications over the last 42 years. c. LEED Electric has not filed for bankruptcy, is not currently in default of business loans and is not responsible for undisputed payments to suppliers or transporters which are over 60 days past due. 11 Section A LEED Electric Inc. Oct. 8, 2021 LS■ � � � City of Seal Beach &.CCY RFP On -Call Electrical Maintenance and Repair Services ELECTRIC LEED Electric, Inc. — Statement of Qualifications In addition to the minimum qualifications for participation in this Maintenance Services Contract, LEED Electric offers: • 42 year history of excellent working relationship with public agencies throughout California • Southern California locally -based operations • Experienced project managers and staff as relates to compliance with goal -oriented projects • Locally hired union workforce with vast manpower capabilities • LEED Electric is certified Small Business Enterprise (SBE) by the State of California Department of General Services, City of Los Angeles, and the County of Los Angeles Office of Affirmative Action Compliance as an eligible participant in the County of Los Angeles Local Small Business Enterprise Preference Program. LEED Electric has prior experience in related projects and is extremely competent in the installation of Electrical, Instrumentation and Control Systems. r 2 1 Section A LEED Electric Inc. Oct. 8, 2021 L.CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Firm Name LEED Electric, Inc. Corporate Office Address 13138 Arctic Circle, Santa Fe Springs, CA 90670 Corporate Phone and Fax Numbers Firm Phone # Firm Fax # (562) 270-9500 (562) 863-5723 Federal Tax ID # 95-3337191 Business Type S -Corporation Established 3/1/1979 in California DUNS No.: 09-916-2901 CAGE Code: OXJH1 0048-131380000-1 Exp. Date: 06/30/2022 Business License City of Santa Fe Springs, California License No. 379096 Exp. Date: 07/31/2023 State of California Contractors State License Board Contractor License A - General Engineering Contractor C-10 - Electrical Contractor DIR Contractor Registration DIR Registration No. 1000004633 EXP. Date: 06/30/2022 County of Los Angeles (LSBE) #139996 Exp. Date: 04/30/2022 SBE Certification State of California (Dept. of Gen Services) #36862 Exp. Date: 04/30/2022 NAICS 238210 Seth A. Jamali Dinan, Chief Executive Officer Principals/Officers l Annette Iribarren, Corporate Secretary & Controller Darren Roesch, Operations Manager Rodney Dean, Vice -President & Chief Estimator Years with Company Seth Jamali Dinan: 8 years Rodney Dean: 18 years Telephone and Fax Numbers Phone # Fax # (562) 270-9500 (562) 863-5723 Name, Title, Phone No., and Email of Seth A. Jamali Dinan (562) 270-9500 Contact Person for the Proposal sjamali@leedelectric.com Total # of Employees with the Firm 100 WebVen # 13999601 3 1 S e c t i o n A LEED Electric Inc. Oct. 8, 2021 ■ ��� `CCU ELECTRIC CONTACT INFORMATION City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Management: Seyed A. Jamali Dinan — CEO (562) 270-9500 sjamali@leedelectric.com Field Supervisor: Gary Van Eede — General Superintendent (562) 899-8650 GVanEede@leedelectric.com Operations Manager: Darren Roesch — Operations Manager (626) 692-3330 droesch@leedelectric.com Superintendent: Cody Engelhardt — Superintendent (562) 45-5460 cengelhardt@leedelectric.com Project Manager: Kevin Schwab — Senior Project Manager (562) 270-9500 kschwab@leedelectric.com Support Staff. Assist with estimates and project documents. Anthony Santoro — Preconstruction Engineer (562) 270-9500 asantoro@leedelectric.com Terree Rola — Project Coordinator (562) 270-9500 trola@leedelectric.com Foreman Electrician: Edgar Salidvar Ron McClory Marlo Fria Sierra Ron Ellard Sean Eagle Additional Electricians as Necessary: Leed Electric may pull from its many Electricians or request additional Electricians from the Local IBEW 441 Union. 11 Se c t i o n B LEED Electric Inc. Oct. 8, 2021 ■ ��� `CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications RESUMES Led by Seyed A. Jamali Dinan, CEO of the company, the executive management team possesses impressive credentials, critical industry experience and education. The team, which comprises a combined industry experience of over 100 years, provides oversight and proficiency in all key functional areas of the business. Seyed A. Jamali Dinan, Chief Executive Officer: As CEO of LEED Electric, Mr. Jamali Dinan enhances the company's leading posture in the industry by implementing new strategies and technologies in the field and for in-house operations. He is responsible for leading the company into new product development and new market expansion, assuring its continued growth and prosperity. Mr. Jamali-Dinan oversees all aspects of company operations including: estimating, project management, accounting, purchasing, contact administration, project development, customer relations, and employment development for all employees. Mr. Jamali Dinan has over 18+ of experience in the field of general and electrical contracting and provides the intuitive real and nuanced insights needed to detect and assess the most inconspicuous challenges and undefined subtle issues and exact the precise solution for any situation. Mr. Jamali Dinan actively serves as the guiding influence to the entire management team as well as the other members of the firm. Mr. Jamali Dinan obtained his Electrical Engineering degree from the University of Nottingham in the UK in 1999 later on attended the University of Southern California (USC) receiving his MS in Construction Management in 2006. Prior to joining LEED Electric, Mr. Jamali Dinan worked as a Project Manager for over 14 years for a major General Contractor in the US and successfully completed construction projects ranging from $32M to a high end of $225M in value. Rodney Dean, Vice President/Chief Estimator: As Chief Estimator, Mr. Dean is responsible for the oversight and organization deployment of an estimating department, utilizing an in-house proprietary computer estimating system developed over a twenty -six-year period. Mr. Dean joined LEED Electric in 2002 as Chief Estimator and over the ensuing 18+ years has focused mainly on projects in water and wastewater treatment industry. 2 1 Se c t i o n B LEED Electric Inc. Oct. 8, 2021 ■ ��� I.CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Darren Roesch, Operations Manager: The Operations Manager is to oversee all operations, coordinate safety plans, control the manpower, provide for equipment scheduling and insure the production standards and project schedules are met. Aid as a problem solver on the project and interact with the General Contractor, Project Managers and Foreman, insure the proper training and serve as a Mentor for the Foreman in his area of control in order to maintain the High Standards of the Company. Mr. Roesch's educational background includes: I.B.E.W Local 11 Apprenticeship, Microsoft, Certified Systems Engineer, State of Calif. Journeyman Electrician License No. 132051, and Medium Voltage Cable Splicer. Mr. Roesch has 17+ years of experience, primarily on industrial projects consisting of petro/chemical, water/wastewater treatment, heavy manufacturing, internet infrastructure, and TELCOM facilities. He specializes in process control automation and upgrading existing systems and plants. Effective labor management, completing projects on time and under budget, and being orientated toward customer satisfaction are additional strengths. Mr. Roesch joined the LEED Electric Team in 2016, but has worked on several past projects in this field, some of which include: • West Basin Municipal Water District, West Basin Phase V Expansion, where he worked as a Superintendent for the Phase V expansion from 20 MGD to 60 MGD and received an Electrical Excellence Award for the project, and the project contract was over $5 million dollars. • Castaic Lake Water Agency, Rio Vista Water Treatment Plant Expansion Project, he worked as a Superintendent in charge of a crew of Foreman and Journeyman Electricians for the construction of a treatment plant electrical and instrumentation expansion, and again was awarded an Electrical Excellence Award for the project, and the contract amount was over $7 million dollars. • Metropolitan Water District of Southern California, Joseph Jensen Water Treatment Plant, he worked as a Superintendent, in charge of the installation Fluorosilicic acid upgrades, new chlorination storage & treatment facilities in a project valued at over $8 million dollars. Mr. Roesch is a valued addition to the LEED Electric team, starting out as our Superintendent and receiving the promotion to Operations Manager, he continues to lead, learn, educate and mentor others with his extensive knowledge of water and wastewater treatment facilities and has helped insure the growth of LEED Electric. 3 1 S e c t i o n B LEED Electric Inc. Oct. 8, 2021 ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Gary Van Eede, General Superintendent: Mr. Van Eede has 28 years of experience. Primarily on industrial projects consisting of petro/chemical, water/wastewater treatment, heavy manufacturing, internet infrastructure, and TELCOM facilities. He specializes in process control automation and upgrading existing systems and plants. Effective labor management, completing projects on time and under budget, and being orientated toward customer satisfaction are additional strengths. As Superintendent his role is to Manage day to day field activities on multiple projects; Detailing and problem solving on design build projects. Assisting daily in scheduling and planning of projects; Safety and QC ongoing daily; management of field installations and field staffing requirements. His Education and Experience: CSUDH Construction Management, Cerritos College — Structural Welding Technology, Industry Tenure: 30 years, Professional Affiliations: IBEW Local 11, Certifications: State Licensed Electrician No. 109612, City of Los Angeles Certified welder License # P027427, EPRI Level 2 Instrument technician, Attributes Relevant to Water and Wastewater Facilities: Large project Microfiltration and RO membrane experience, Extensive Design -Build experience and Multiple expansion projects successfully completed in operating facilities. Francisco Miranda, Superintendent: Mr. Miranda is a United States Marine Corp Veteran. His electrical education was obtained at Electrical Training Institute. He comes to LEED Electric with 17 years of experience. His experience is vast, but he has primarily worked on petro/chemical, water/wastewater treatment facilities, heavy manufacturing, internet, infrastructure and Telcom facilities. He specializes in process control automation, upgrading existing systems, electrical/instrumentation, and motor control. Mr. Miranda prides himself in effective communication, customer satisfaction, building relationships with the client and contractor/trades, he effectively manages daily project activities, meets deadlines and utilizes resourcesefficiently, so that projects come in under budget. As a Superintendent his role is to oversee the daily project activities on multiple projects, quality control, detailing and problem solving on design -build projects, field installation, and field staffing requirements. Mr. Miranda's professional affiliations include: IBEW Local 11 and National Electrical Contractors Association. Certifications: State Licensed Electrician No. 141714. 4 1 S e c t i o n B LEED Electric Inc. Oct. 8, 2021 ■ ®�® ImCCu ELECTRIC Cody Engelhardt, Superintendent: City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Mr. Engelhardt joined the LEED team in July 2020, as our Orange and Riverside County Superintendent, he is a state certified, journeyman electrician with over 10 years of experience in the electrical industry. The projects that Mr. Engelhardt has been involved with have ranged from small single -owner operations to Fortune 500 companies. Mr. Engelhardt is a goal -oriented individual with a customer service focus, he thrives in high energy, fast -paced work environments and enjoys working with others. His background includes all facets of electrical construction from ground up, to tenant improvement projects and service jobs as a journeyman and a foreman electrician. Mr. Engelhardt is extremely organized and adept in keeping records from project tracking to crewmember staffing logistics. Some of the projects Mr. Engelhardt has completed and/or been involved with are Tustin Fire Station #37, Berth 200 PV System, Vista/ Valley Substation Control Building for Southern California Edison, Crafton Hills Pump Station, as well many more, such as Irvine Valley College - Technology Building, BBraun Pharmaceuticals - Mixing Tank Replacement 2017 & 2018. His qualifications are: California State License Number #153070, OSHA 10 & 30, First Aid/CPR trained, Heat Illness, Are Flash/Energized Work, QSP and Confined Space trained. Mr. Engelhardt is a great leader to our Orange County crews. Kevin Schwab, Senior Project Manager: Mr. Schwab started at LEED Electric in April 2019 and comes to us with over 40 years of experience in the Electrical Industry, some of his qualifications are noted in the latter of this statement following his career history, and He has been in past positions as Division Management and Business Development, Estimating, Purchasing Cost Management, and Logistics. Mr. Schwab supports the company as senior project manager bringing management level support to division personnel including estimators, project managers and superintendents, as well as interface with other trades for Electrical systems installations; Water/Wastewater, Oil and Gas, Underground Utility, Utility Grade Solar, Electrical Systems Infrastructure. Provide management level support to division personnel including staff management and training. Some of the projects Mr. Schwab has completed as Project Manager are: Los Alamitos High School Infrastructure Upgrade $ 10.5 Million, LA BCA DC Tillman Power Upgrade $ 7.7 Million Prime Contract MV Service and Infrastructure, OCSD P2 Demolition and UPS System Upgrade $4.8 Million, LACSD San Jose Creek $ 1.8 Million Sodium Hypochloride Upgrade, City of Torrance Amie Basin $485,000 Flood Control Upgrade, LACSD Carson UV Demonstration Service Upgrade Prime $585,000 and EBX II Craton Hills Pump Station Upgrade $ 10.8 Million. As evidenced by his many years of successful employment in the industry and extensive training which includes IBEW Local 11 Member, Accubid, Primavera OSHA 30, TWIC Certified, Master/JW Electrician Certification and possessing his own C-10 Electrical Contractors License, he brings skilled professional abilities in multiple fields of performance to each project. As a manager, he has the interpersonal skills needed to lead and direct others, while maintaining the integrity and timing of the overall project. 5 1 S e c t i o n B LEED Electric Inc. Oct. 8, 2021 ■ ��� S.CCY ELECTRIC Michael Sanchez, Senior Project Manager: Mr. Sanchez started at LEED Electric in August 2020 and comes to us with 24 years of experience in the Electrical Industry and joins this team as a Senior Project Manager. He spent most of his career as a Senior Project Manager working for Rosendin Electric where he managed projects from $2M to $10M. Mr. Sanchez, has also served as reputable operations manager, senior project manager, field superintendent, and foreman with more than 24 years of experience directing new development, expansion, and renovation initiatives for a number of top-ranking electrical contractors. Consistently meeting key project deliverables while ensuring superior quality and client satisfaction. Talented communicator, with demonstrated success in building valuable relationships with personnel, vendors, clients, city officials and government entities. Expertly manages multi -million -dollar projects for a wide range of sectors including transportation, municipal, hospitality, office, residential, gaming, retail, education, and healthcare. Areas of expertise include: Electrical Contracting Operations, Project Lifecycle Management, Contractor Management, Quality Assurance Team, Leadership, Recruitment, Training & Development, Budgeting & Estimating, Planning, Procurement Blueprints & Specifications, Safety Awareness, Scheduling, Client & Vendor Management. Some of his career background consists of City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications • Operations manager for the Ontario office location managing Project Management and Field Operations Managed numerous Projects between 250k- 7M as a SR. PM. Managing 3 PM's, 3 PE's, 2 PA's, Warehouse, Prefab, 18 Foreman, 50-100 field employees. Bid reviews, Cost to complete for 20+ projects. Directly report to Executive Vice President. • Senior Project Manager on Kaiser Hospital Projects $42M+ DB/DA and High rise in Downtown LA 12th & Fig. Signage. Manage all aspects pertaining to electrical portion of project, report to the Division Manager • Managed 3 large projects simultaneously all valued at $IOM+ • $142M initiative to expand the 2M+ sq. ft. 2.4B$ McCarran International Airport Facilitated project startup within 90 days of notice to proceed; included purchase orders & submittals for all material deliverables. 6 1 S e c t i o n B LEED Electric Inc. Oct. 8, 2021 ■ ��� IWCCY ELECTRIC Paul Bergeron, Senior Project Manager: City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications Mr. Bergeron joined Leed Electric in December 2020 with an extensive background of 13 years of experience in the electrical industry by completing his Journeyman Wireman Program at Sanitago Canyon College in 2007 and receiving is certified general wireman license. Some of his education accolades are Electrical Project Supervision (EPS) 1-3, OSHA 30 -Hour Certification, First Aid and CPR Certification, Anti -Harassment Training, Pricing and Negotiating Change Orders and Claims Like a Pro Seminar, and Procore — Project Manager: Core Tools Certification. Some of the aspects he handles at Leed are Manage Project Engineer and Other Support Staff for Multiple Projects, Develop, Review and Coordinate Schedules with Owners, General Contractors, Subcontractors, and Field Superintendents, Review Bid Documents for Schedule Impacts, Conflicts with Other Trades and Potential Manpower Issues, Request, Review and Process Potential Change Orders, BFI's, ASI Drawings and Submittals, Provide Detailed Labor and Material Take-Offs/ROM's/Estimates/Change Orders for Scope Changes and Bids, Order Buy -Out Quotation Materials and Systems, Monitor Drawing Approvals and Schedule Material Arrivals, Coordinate the Procurement, Delivery, Installation, QA/QC, Testing, Startup, Commissioning and Close -Out of Multiple Projects, Provide Acceptable Billing Breakdown and Monthly Billings to the General Contractor and Coordinate with Various Jurisdictional Authorities and Update Owner on Inspections, Shutdown Requests, Job Walks, Schedule and All Other Activities. Some of the project he has worked on are: • OCWD — YLWD — HQ PFAS $2,489,063 • SoCal Gas — Industrial Electrical Services $4,000,000 • SDGE — Industrial Electrical Services $1,000,000 • LACDPW — West Coast Basin Barrier Project Unit 13 $1,021,941 • LACDPW — Low Flow Diversion System Wide Update $1,150,000 • IRWD — ZARRPS — Zone A Rattlesnake Reservoir Pump Station $2,287,000 • TIWRP — CIP 8170 — CISCO 11 — HWRP IPS Screw Pump No. 9 Replacement $35,654 • TIWRP — CIP 8542 — CISCO 10 — Advanced Water Purification Facility Phase 1 Chemical Piping Replacement $389,897 • TIWRP — CIP 5249 — CISCO 10 — EPP Pump #3 Train Rehabilitation $160,887 • City of Oceanside — Oceanside Beach Operations Facility and Restrooms Project Mr. Bergeron has improved his skills in this industrial and knowledge and connections while working for other major competitors in this industry such as starting out as a Project Engineer at Morrow -Meadows Corp, then Assistant Project Manager and finally to Project Manager over a 10 -year career while at Morrow -Meadows, as well as working for Anderson and Howard and Giannelli Electric and Whiting -Turner Construction for a few years before coming to Leed. We look forward to all that Mr. Bergeron has to offer and utilizing his extensive network base, skills and knowledge of this industry in the many years to come. 7 1 S e c t i o n B LEED Electric Inc. Oct. 8, 2021 ■ ��� I.CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric,1nc. —Statement of Qualifications Antonio Bracamontes, Project Manager: Mr. Bracamontes joined LEED Electric, starting in August 2015, but he has over 18+ years' experience in the Industrial Electrical Project Management Field specializing in water and wastewater treatment facilities construction management. Mr. Bracamontes currently working as a Project Manager for LEI on several of its current projects and has also managed several industrial water/wastewater projects in the past some of which include: • City of Cypress Department of Public Works, Myra Ave. Pump Station No. 2 Reconstruction, worked as a Project Manager, interfacing with the Owner and General Contractor to coordinate the installation of a new Motor Control Center, VFDs, Pumps, a SCADA System and backup generator at a 45 year old pump station rehabilitation to prepare for the 100 year flood. • Irvine Ranch Water District, Orchard Hills (PAI) ILP Turnout, worked a Project Manager to coordinate and oversee the installation of flow meters, pressure transmitters, an antenna mast, site lighting and electrical conduit and wiring for the new station for the water district. • Irvine Ranch Water District, Zone 3 to 4 Domestic Water PRV Site Northwood Reservoir, again worked as a Project Manager to oversee the field construction of the PRV station for the water district. Coordinated the installation of new MOV's, a service pedestal, pumps, and instrumentation. Mr. Bracamontes has Bachelors of Science in Electrical Engineering, emphasizing in Communication from the California State Polytechnic University, Pomona. Prior to joining LEED Electric, Mr. Bracamontes worked as a Project Manager for over 13 years for another local contractor, Beard Electric in Santa Fe Springs and 2 years working as an Electrical Systems Engineer with Trams International, Inc. before joining the Leed Electric team. 8 1 S e c t i o n B _ LEED Electric Inc. Oct. 8, 2021 E � � � City of Seal Beach to CCY RFP On -Call Electrical Maintenance and Repair Services ELECTRIC LEED Electric, Inc. — Statement of Qualifications Jerry Romero, Project Manager: Mr. Romero joined LEED Electric in June 2018 to be a part of its Project Management Team. Mr. Romero has over a combined 23 years of experience in the electrical and instrumentation & controls industry. This includes site field superintendent positions in the heavy industrial construction sector, with a specialty in the water/wastewater, chemical plants, booster and lift stations. Mr. Romero has managed many industrial water/wastewater projects, some of which include: • City of Perris chemical treatment plant: This project consisted of a new freshwater treatment facility. Included in the scope of work were underground duct banks, manholes, service board, MCC, Pumps, instrumentation & controls, SCADA, PA and fire alarm systems. • City of Long Beach Haynes facility: This project was a design build reverse osmosis plant. Included in the scope of work were new pumps, VFD's, MCC's, motor operated valves and instrumentation and controls. • City of Anaheim, Lenain Water Treatment Plant, Contract Value: $2.3M, Installation of Switchgear, Motor Control Center, VFD's, Instrumentation and Control Panels, and Lighting. Role: Project Manager • Mission Village Temporary Pumping Plant and Force Main for new construction in the Valencia area. Installation of conduit, wire, Switchgear, Motor Control Center, new VFD's, Instruments, Control Panels and Lighting for a ground up new construction pump facility. Contract value: $664,488, role was Project Manager. Mr. Romero experience of accountability included submittals, material procurement, scheduling of field crews, as well as sub -contractors and startups. 9 1 S e c t i o n B LEED Electric Inc. ! Oct. 8, 2021 ■ ��� 1.CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Karen Ankenbauer, Assistant Project Manager: Ms. Ankenbauer has been in the electrical construction industry since 1999, starting at a small shop in the Los Angeles area (Angeles Electric) that mainly did TI and commercial work in the LA and Long Beach areas. Some of the project highlights at Angeles Electric were the: Marion Davie Rehab and Reuse project in Santa Monica, Solar project at Burbank Airport and four floors at the Doctor's Hospital project. Some of Ms. Ankenbauer's responsibilities at Angeles included (not limited to): Billing, Collections, Completing Prequalification's, Preliminary Notices (and tracking 30, 609 90 days after final labor so we didn't lose our lien rights), T&M pricing and billing, Change Order processing and updating SOV's for billing. From Angeles Electric Ms. Ankenbuauer went to Doty Bros. where her primary functions were Bid Coordination, Job Walks, Some Estimating, submittals, and following through on contract documents, some projects were the Morris Dam, Oxnard Advanced Water Purification Plant, and Weymouth MWD. From Doty Bros. Ms. Ankenbauer went to Neal Electric where she focused on change orders, billing, collections, assisting the division manager, Prequals, PLA documents, writing subcontracts and major PO's following through with the PLA documents for compliance, bid advertisements, and office facilities. Some of the highlight projects at Neil were the Haynes Power Plant, Long Beach Pumping Plant, & San Jose Creek. After Neal Electric Ms. Ankenbauer went to A -C Electric as a Project Assistant where she did everything from contract routing, PLA documents, submittals, change orders, RFI's, job walks, pre - job orientation meetings, bid/contract scope reviews with the PM's, major PO buyout reviews, billing, collections, assisting PM's with their projections. Some of the project highlights were the Jockey Pump at Port Hueneme, Roosevelt High School (LAUSD), Santa Ana Jr. College Student Center. Programs: Textura & Procore License: Notary, Completed: Basic Estimating at LA NECA. Engineer: Mr. Sepehr Fanaeian has been with LEED Electric since August 2017. He has 9 years of experience in Electrical and Control Engineering field. He worked for 5 years with Science Instrument Co. in Baltimore, Maryland as well as overseas in Haifa, Israel at the Baha'i World Centre in the Engineering Department - Electrical/Control Engineering Management Team for more than 4 years of his stay there. He has extensive experience on electrical system project and upgrading of control and security systems. Mr. Sepehr Fanaeian has a Bachelor of Science in Electrical Engineering Degree, with Electronics Minor from BM — online University in Tehran, Iran, and he continued his post -baccalaureate at the University of Maryland — UMBC. Mr. Fanaeian is responsible for the production of project submittals, from generation to approval and tracking these documents, field RFI's, and supporting the Project Manager, Superintendent and Field Foreman, attending meetings, generating schedules and tracking materials and gear to ensure on-time delivery. 101 Section B LEED Electric Inc. Oct. 8, 2021 City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications Abdel Hamid, Project Engineer: Mr. Hamid joins the Leed Electric team most recently in October 2020 possessing a strong education Bachelor of Science in Electrical Power Engineering Technology, University of Houston, College of Technology, with experience and skills that consist of. Proficient in MS Office, Bluebeam Revu, AutoCAD, Electrical Circuit & Power Systems Analysis, Basics of C++ Programming, Matlab, MIPS, VHDL, PLCs, Altium Designer, AutoCAD, SAP and Accubid. He plans to apply his technical knowledge, analytical skills, and achieve hands-on experience in a leading organization while expanding his electrical design knowledge and workplace competency through continuous research and training. Additionally, his previous job facilitated in him being committed to quality, continuous improvement, and the ability to function effectively as a member of a team with the highest professional and ethical standards. He comes to us with skills as a Project Engineer managing multiple low voltage subcontractors, submittal processing, BFI's, coordination of trades, Oversee QA/QC procedures for low voltage systems and experience assisting with change orders and negotiations for added scope. Anthony Santoro, Preconstruction Engineer: Mr. Santoro started with Leed Electric in August 2015, although his career in the electrical industry began with Beard Electric in Santa Fe Springs, California. He has over 10 years' experience working as an assistant PM/Suport Staff at Beard p�- Electric and looks to take on more challenging rolls now at Leed Electric in the coming years of his career. He worked as an assistant PM on several water and wastewater projects working with fellow employees Mr. Bracamontes and former co-worker Mr. Nanthavong while at Beard Electric, generating submittals, RFI's and assisting with purchasing and change order management. Currently with Leed Electric Mr. Santoro works on submittal packages for both in house submittals and packing vendor submittals along with processing all of the Time and Material Estimates / Change Orders and supports the Project Managers, Field Operations Manager and Executive Supervisors with delegated tasks, from estimating support, bid packages, and prequalification, to pre -con responsibilities. Mr. Santoro also helps in processing work orders for the current On -Call Operations Telemetry System Maintenance Services Project with LACDPW in the capacity of supporting the field crewmembers as well as office management staff, to ensure purchases are made on time and work orders are scheduled and completed in a timely and professional manner. Mr. Santoro graduated with an Associate's Degree in Administration of Justice from Long Beach City College and looks to further his knowledge of project management while working with the Leed Electric team. 111 Section B LEED Electric Inc. Oct. 8, 2021 27 N f � � City of Seal Beach S.CCY RFP On -Call Electrical Maintenance and Repair Services ELECTRIC LEED Electric, Inc. — Statement of Qualifications Daniel Flores, IBEW Certified Electrician: General Foreman Electrician: Mr. Flores has been with Leed Electric, Inc. since 2004, and has completed the IBEW apprenticeship program and worked for Leed Electric as an Apprentice and graduated to Journeyman and was promoted to Foreman then General Foreman. Mr. Flores is OSHA 10 and 30 certified and completed Confined Space Training, and graduated with an Associate Degree in Liberal Arts from Santa Monica College. He has worked on and completed several projects for Leed Electric which some are listed here: • LACDPW Compton Creek, Foreman demo of existing conduits, wires and controls at lift station facility to run new conduit and wire for new engines and pumps installed at the facility by the general contractor. Installed gas detector system and propane gas backup for engine operations, conducted field testing and started up system. Installed field site lighting and inside pump station, conducted field meetings and coordinated work with project manager and general contractor, the project concluded in 2015. Position: Foreman • LACDPW Terminal Island WRP Tertiary Filters Rehabilitation, Foreman Installed conduit systems and wiring to new MOV's at the sand filter area, installed new control panel for new MOV's and pulled analog, control and power wire to (64) new MOV's, the project was completed in 2015. Position: Foreman • West Basin Municipal Water District Edward C. Little Water Recycling Facility Clean -in -Place Waste Discharge Project, Foreman Worked on field layout and material procurement and installation. Made field installation schedule for project, conducted safety meetings, started the project from underground conduit installation and up, installed utility conduit run, installed new Switchgear, MCC and lighting. Ran conduit and wire in the pump station and treatment system, tested system and startup conducted. Managed installation and coordination with owner and general contractor to complete the project in late 2018. Position: Foreman • City of Los Angeles, Venice Dual Force Main and Generator Installation, General Foreman, he has overseen the installation from underground PVC conduits to above ground GRC and PVC Coated conduits. He has assisted in the redesign and installation of (2) large Cummins generators. Installation of new control panels, Switchgear, Instrumentation and Controls, The project completed in late summer 2019. With the training and experience working for Leed Electric for so many years Mr. Flores is qualified for any wastewater project that LEI is awarded and in currently supervising several LEI projects in his General Foreman capacity where he will oversee a Foreman and his crew to ensure the project is completed on time and per spec. 121 Section B LEED Electric Inc. Oct. 8, 2021 ■ ��� `CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Edgar Saldivar, IBEW Certified Electrician: General Foreman Electrician: Mr. Saldivar has over 18 years of Commercial and Industrial experience. Adept in performing electrical installations, maintenance, and repairs in water plant facilities; knowledgeable in all areas of the national electrical code; and excel in analyzing and solving problems with various electrical controls and systems. For the past 5 years, as a Foreman, Mr. Saldivar has completed several projects in Los Angeles County. The following projects executed by Mr. Saldivar are as follow: • San Jose Creek Water Reclamation Plant, in Whittier, installed a Unit Substation 1C2-lD2 and associated electrical duct banks, cable trays, manholes, pull boxes and 5-kv conductors. At the Sludge pump station, I coordinated the installation of VFCs, switchboards, panelboards, transformers, Control Panel and instruments. • Terminal Island Water Reclamation Plant: Microfiltration, reverse osmosis and chlorination underground duct banks, manholes and Prefab Electrical Rooms. Control Panels and all Instrumentation such as FITs, PITS, DPITs, LITs AITS, • Maywood Mutual Water Company, in Huntington Park, the electrical room with ATS and Generator was modernized. Installed new Backwash Pump, Reclaim Pump, Sludge Pump Microfiltration vessel with MOV§, DPITs, FITs and PITs. • Mesa Water District, Well Automation and Rehabilitation Project at Mesa Wells 1, 3, 5, 7 and 9 spread across the city of Costa Mesa. The work included, the upgrades of the wells, pump replacement, gas engine replacement, general electrical equipment replacement, new emergency generators, construction of new chemical storage and feed systems area, replacement of wellhead piping, instrumentation upgrades, and site security improvements, with the contract constraints that only 1 well could be offline at a time and there was a schedule as to when it was okay to take wells offline. Work for this project took place in 2 shifts with Mr. Saldivar working as the General Foreman, overseeing both day and night activities due to project requirements. Mr. Saldivar is a Certified General Electrician and has obtained a C-10 state license and has completed the following courses; code, instrumentation, and foreman courses at Electrical Training Institute through IBEW. Edgar has the skills to complete any instrumentation project and is currently working for the City of Santa Ana as the maintenance contractor of choice for several of the cities Pump Stations and Treatment Systems. As well as working for Mesa Water District in a service contract for their reservoirs and has expertise in this industry that is very hard to match. 131 Section B LEED Electric Inc. Oct. 8, 2021 ■ ��� `CCIJ ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Joseph Evanilla, IBEW Certified Electrician: General Foreman Electrician: Mr. Evanilla came to Leed Electric in early 2020 as a General Foreman Electrician, with more than 35 years of experience planning, developing, and implementing construction projects. Extensive understanding in Public Works Water Production. Mr. Evanilla has spent his careering working for A & B Electric Company, then over to Morrow -Meadows Corp before joining Leed Electric. His career and training highlights are EPRI Certification, AC/DC power and control systems, Electro -mechanical proficiency, Complex issues management, Understanding of client business requirements, Strong customer focus, Works well in team environment, Blueprint takeoff, Project layout, Control schematic production and an Extensive knowledge in electrical tools and equipment. Some of the many projects Mr. Evanilla has completed are listed here: LAXFUEL Corporation, 4 TANK Project 2019, Metropolitan Water District, Joseph Jensen WTP Plant Electrical Upgrades Stage IA 2018, City of Chino, Eastside Water Treatment Plant 2016, Three Valleys Municipal Water District, San Antonio Spreading Grounds 2014, City of Brea, La Florista Sewer Lift Station 2014, City of Covina, Charter Oak Reservoir 2014, Fontana Water Co., Sandhill Hydroelectric Generators Plasent 2013 and Rancho Cucamonga Water District, Arthur Bridge WTP 2013 and many more dating back to 2003. Mr. Evanilla is a valued addition to the Leed Electric team with his unmatched experience, skills and leadership qualities. Michael Marshall, IBEW Certified Electrician: Foreman Electrician: Mr. Marshall joined Leed Electric in 2016; he completed the IBEW Five Year Apprenticeship Program in 2016. Mr. Marshall has previous experience working for Neal Electric working on water and waste water projects. When Mr. Marshall joined Leed Electric in 2016 he began working on several water and wastewater treatment projects in varies stages of completion. Some of the projects Mr. Marshall has completed are the following: • Los Angeles Wastewater Integrated Network Systems (LAWINS), working with the integration at Hyperion Treatment Plant under the supervision of our General Foreman Instrument Tech. • 2017 West Coast Basin Barrier Telemetry Project, for Los Angeles County Department of Public Works, upgraded the existing telemetry system by adding new PLC's with battery backup, re - terminated the system to work with the new interface. For the West Coast Barrier reach of the Seawater Barrier System for LACDPW. Position: Journeyman • Currently working on the Seawater Barrier Maintenance Contract as the dedicated Certified Electrician, when WO's come in he reviews the requirements and completes the necessary work for the Los Angeles County Department of Public Works. Installing new sensors, troubleshooting, working with our subs troubleshooting communication issues and solving these problems so that County may have a working monitoring system. Mr. Marshall has also worked on projects such as the West Basin Project Phase V, LAX/Crewshaw Transit Corridor and has some experience in Photovoltaic Systems in his training. While at Leed Electric he has worked under the direction of Miguel Chavez working on the Telemetry Projects recently completed by Leed Electric and has valuable expertise at the Barrier Systems. 14 1 Section B LEED Electric Inc. Oct. 8, 2021 ■ ��� `CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Sergio Hernandez, IBEW Certified Electrician: General Foreman Electrician: Mr. Hernandez completed the IBEW Apprenticeship Program; He has over 11 years of electrical experience in this field. He joined Leed Electric in 2016 working on several water and wastewater treatment projects in varies stages of completion. Some of the projects Mr. Hernandez has completed are the following: • 2010-2012 Morris Dam provide and install switchgear, MCC, PLC, Control Panels, 6 MOV's, FIT's, PITs, Generator, and Lighting for the Dam. Position: Journeyman • 2013-2016 San Jose Creek Ras Pump Station - Install substation, Manholes, MCC, PLC, Control Panels, VFC's, FIT's, LIT's, PIT'S, and installed medium voltage cable. Position: Journeyman • 2016 Long Beach Pump Station- installed Bus Duct, switchgear, MCC, PLC's, Control Panel's, VFC's, 6 MOV's, vibration switches, and fire alarm. Position: Foreman • 2017 -Current Santa Anita Dam Spillway Modification Project, Position: Foreman, overseeing the installation of underground and above ground conduits, above, below and on the Santa Anita Dam face. Safety is his top priority while supervising this projects crew. The work consists of installing Lightings, as well as helipad lights, Manual Transfer Switch, UPS, Generator Connections, Cable Tray Systems and Fiber Optic Cable and Hardware. Mr. Hernandez has a solid work ethic and keeps close eye on safety performance of not only his crew, but of crews working alongside so as to ensure nothing dangerous goes on with a potential for injury. Mr. Hernandez is an asset to LEI. Christian Tomren, IBEW Certified Electrician: Foreman Electrician: Mr. Tomren joined Leed Electric in 2017; he completed the IBEW Electrician Program in 2009. He joined Leed Electric in 2017 working on several water and wastewater treatment projects in varies stages of completion. Mr. Tomren has many qualifications, which are: CA General Electrician Certified 2008, Advanced Lighting Control 2013, Solar PV/Installer 2009, OSHA 10 & 30, First Aid, CPR Trained, Confined Space Certification and can operate several different types of construction equipment with different certifications. Some of the projects Mr. Tomren has completed are the following: • Mr. Tomren completed the MWD Advanced Water Treatment Demonstration Facility, General Foreman Electrician. • CIP 5233 Terminal Island Advanced Water Purification Facility Doubled Capacity of Clean water to 12 MGD. Installed two new 200HP VFD. New MF Facility and Electric Room with 2 60 HP VFD's. New RO Facility and Electric Room with 2 500HP VFD's. New AOP UV System Facility. 10 Chemical Metering Pumps and new Sodium Hypochlorite Facility. 3 125 HP Product Water VFD's. New UPS System for 8 PCM's. 3 New Man Holes and Associated Duct Banks. 8 PCM Demo and Installation of New PCM's. Managed 21 Electrician's during the peak of the project. New MCC inside main electric building. Position: General Foreman Electrician • Carbon Canyon Water Recycling Facility, PLC Upgrades, Install New Conduit and Wire, 4 New PLC's and Cutover 1 train at a time. New Server Room. Position: Foreman Electrician Mr. Tomren has the proven ability to schedule/manage employees while maintaining maximum productivity, and is an excellent addition to Leed Electric and is prepared for any project, and is a valued asset to have a part of our team, ready to tackle what may come ahead. 15 IS e c t i on B LEED Electric Inc. Oct. 8, 2021 ■ ��� ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Sean Eagle, IBEW Certified Electrician: Foreman Electrician: Mr. Eagle joined Leed Electric a few years back and has been a Union Electrician since 2011 with Orange County IBEW Local 441. His education began at Brooks College where he received his Associate's Degree in Programming and Networking. Shortly after he began his electrical education with the union where he became a State Licensed Electrician. Mr. Eagle also has several certifications, those in CPR and first aid, High -reach fork lift, and Hilti powder actuated gun. His job responsibilities in the past have included, Chapman University, Mary Pickford Theater, Fox Studios, solar in Huntington Beach Civic Center, utility yard and library, solar at George F Bailey Detention in Chula Vista, solar at Kaiser in Yorba Linda and solar in schools, new construction High Rise buildings in Fashion Island and Irvine, commercial Tenant Improvements, and multiple parking structures. Mr. Eagle joined Leed Electric in 2017 as a 5th year apprentice and became a Foreman officially in September 2018. He has lead projects at Mid -Basin, Orange County Water District, and Temescal Valley Water District Water Reclamation Plant Phase IV Expansion as well as assisted at Mesa Well Automation, Mesa Water District. Mr. Eagle is currently leading the Yorba Linda Water District HQ PFAS Water Treatment Plant located in Yorba Linda for the Orange County Water District. 161 'Section B LEED Electric Inc. Oct. 8, 2021 a]! � \ )( § ! f \ r me § _ / 0 \ \ < E k / \ \ 45 k k �0 k � 0 7 i| { f ( d § 2 ] k \ \ )= )r p</ / E k 0 - 0 \ ) ) . 7 } \ cri Z15 �w { }- § 2 • & ) \ M J } W |� \ )( oJ ■ , =.0 0 ■ ��i `CCU ELECTRIC C. Understanding/Approach City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications LEED Electric Inc. is an experienced and highly -recommended full-service commercial and industrial electrical, control & instrumentation contractor. The company has a reputation for completing projects on time, within budget and to the client's satisfaction. The company's comprehensive knowledge of new technologies combined with the highly trained staff and more than 42 years of experience performing heavy contracting work make LEED Electric a provider of choice. LEED Electric began operations in 1979 performing work at oil refineries, chemical plants and aerospace facilities. Later began doing public work for various municipal and county facilities on pumping plants, water treatment plants, and sewage treatment plants installing power and control systems, automation/measuring systems. LEED Electric has provided quality services through a long 42 year history with the County of Los Angeles, the City of Los Angeles, County of Orange, the Metropolitan Water District of Southern California, the Department of Water and Power, Long Beach Water Department, City of Santa Monica Water Resources Division and most recently the Water Replenishment District (WRD) of Southern California and Los Angeles Wastewater Information Network System (LAWINS). Leed Electric, Inc. is a qualified Small Business with the State of California Department of General Services as well as County of Los Angeles Office of Affirmative Action Compliance as an eligible participant in the County of Los Angeles Local Small Business Enterprise (LSBE) Preference Program. Numerous other public works projects have been successfully completed for virtually every local City and/or County governmental agency including Orange County Water District, Orange County Sanitation District, Los Angeles County Sanitation District, State of California Water Resources and other state agencies. LEI currently holds Electrical Maintenance Service contracts with the County of Los Angeles Seawater Barrier Telemetry Maintenance, Long Beach Water Department, WRD of Southern California, City of Santa Ana, City of Santa Monica, City of Montebello and Mesa Water Agency, we look forward to working with the City of Seal Beach. Currently LEED Electric holds the Electrical Maintenance Services for: • Los Angeles County Department of Public Works — Seawater Barrier Maintenance — Adam Lee • Los Angeles County Department of Public Works — Rubber Dam System Maintenance — Sarkis Zargaryan • Water Replenishment District of Southern California — Electrical Maintenance — Tom Knoell • City of Santa Ana — Electrical Maintenance — Juan Ramirez • Mesa Water District — Electrical Maintenance Services — Dustin Burnside • . Recently awarded: Chino Basin Desalter Authority Electrical Maintenance and City of Chino Hills Electrical Maintenance. LEED Electric's approach for our maintenance project is based on individual work order requests. Below is the step by step work plan for each task: 1- Request is made for service as Time and Material or a site visit will be required to assess the scope of work and material and labor requirements. 2- Leed Electric submits a cost proposal with detail labor and material, specific inclusions and exclusions for the specific task, either based on a site visit assessment, photos or a detailed descrition of the work required. Here is what may be involved on a maintenance request (Examples Only): a. Electrical and light testing tasks that can be completed by Leed Electric's technicians. b. Control System or communication system task that can be completed by a subcontractor or a joint effort between the two entities. C. Materia_ 1 Purchase from a specific supplier. 11 S e c t i o n C LEED Electric Inc. Oct. 8, 2021 ■ ��� City of Seal Beach S.CCY RFP On -Call Electrical Maintenance and Repair Services ELECTRIC LEED Electric, Inc. — Statement of Qualifications d. Subcontract work depending on the nature of the work order. That could include, general construction work, concrete cutting, instrument calibration and etc. e. All work order will have a cost proposal back up from subcontractors or other suppliers. 3- City to review the cost proposal submitted and either approve, reject or request modifications. 4- Upon approval of the cost proposal LEED Electric may take the following actions: a. For Material Only, order/s will be placed, and ETA will be provided b. For Labor Only a mutually agreed date will be scheduled, and a calendar invite will be sent via MS 365 to all parties involved. C. For Maintenance, a request will be sent to the subcontractor and a mutually agreed date will be schedules. d. For Labor and Material, material order will be placed, and a mutually agreed date will be scheduled upon receiving of the material. 5- Upon completion of a maintenance request, a copy of the daily report will be emailed to the city with the following possible end results: a. Work order was completed and tested per the hours and material submitted on the original cost proposal. b. If LEED Electric finds out there is more hours needed to complete a work order, upon completion of the maintenance request, adjusted hours and cost proposal report will be submitted. C. If work is to be completed on a Time and Material basis, a cost proposal with labor and material from stock or vendors will be submitted based on the hours used and material used. 6- At the of each work request or month, a schedule of values will be submitted to city's PM for review and approval. Upon approval of the draft Schedule of values, a formal progress invoice will be submitted to city's Fiscal Division. 2 1 Section C LEED Electric Inc. Oct. 8, 2021 ■ ��� `CCU ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Project No.1 Project Name On -Call Consultant Services for the Los Angeles Wastewater Information Project Name Network System (LAWINS) Location Playa Del Rey, CA Owner City of Los Angeles, Department of Public Works, Sanitation Bureau Project Manager Name Tim Makela E-mail and Telephone No. 310-648-5920 timothy.makela@lacity.org Contract Value 7,300,000.00 City of LA, Dept of Public Works, Sanitation Bureau (including change orders) Demolition of existing wire and conduit from filters. Furnish and install new Brief Description of Firm's Scope of Instrumentation and System Integration for Honeywell DCS Cutover, Testing Completion Date of over 15,000 field instruments and replacement of over 100,000 LF of Work for the Project Instrument and Power Cable (HWRP, TIWRP, DCTWRP & LAGWRP) Completion Date December 2019 Project No. 2, Project Name Terminal Island Water Reclamation Plant Tertiary Filter Rehabilitation Location San Pedro, CA Owner City of Los Angeles Depart. Of Public Works, Bureau of Engineering Project Manager Name Sinh Pham (310) 648-6130 E-mail and Telephone No. Sinh.pham@lacity.org Contract Value $ 719,330.00 (including change orders) Brief Description of Firm's Scope of Demolition of existing wire and conduit from filters. Furnish and install new Work for the Project conduit, wire, instruments and RVSS. Completion Date January 2017 11Section D LEED Electric Inc. Oct. 8, 2021 L.CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications Project No. 3 Project Name Hawaiian/B, Wilmington, Fries and San Pedro Pumping Plants Rehabilitation Location San Pedro, CA Owner City of Los Angeles Depart. Of Public Works, Bureau of Engineering Project Manager Name Sinh Pham (310) 648-6130 E-mail and Telephone No. Sinh.pham@lacity.org Contract Value $ 1,106,056.00 (including change orders) $3,496.197.00 (including change orders) Demo of wire, conduit, pumps in (4) City of LA Sewage Pump Stations. Brief Description of Firm's Scope of Installation of bypass and generator systems for all 4 stations, furnish and Brief Description of Firm's Scope of install (12) VFD's with bypass and new PLC and field instruments. Work at Work for the Project all (4) pump station sites was preformed concurrently, pump stations 1700gpm at Hawaiian, 2,350 at Fries, 1,900 for Wilmington and 10,000 at San Pedro. Preformed start up and testing of pump station size. Completion Date September 2017 Project No. 4 Project Name Joint Water Pollution Control Plant Power Generation Facility Upgrade Location Carson, CA Owner Sanitation District of Los Angeles County Chris Larson Project Manager Name (310) 736-8438 E-mail and Telephone No. CLarson@lacsd.org Contract Value $3,496.197.00 (including change orders) Brief Description of Firm's Scope of Electrical, Instrumentation, Programming and System Integration for Work for the Project Wastewater Treatment Facility Completion Date October 2012 2 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Project No. 5 Project Name West Coast Basin Barrier Project Location EI Segundo, Manhattan Beach, Hermosa Beach, Torrance - CA Owner County of Los Angeles, Department of Public Works Project Manager Name Adam Lee (626) 458-6185 E-mail and Telephone No. AWLEE@dpw.lacounty.gov Contract Value $2.586,788.39 (including change orders) $947,658.00 Brief Description of Firm's Scope of Furnish and Install Electrical, Control, SCADA, Instrumentation and Work for the Project Programming for Seawater Barrier Injection Wells and Observation Wells Completion Date January 2013 Project No. 6 Project Name MWD Weymouth Filter Upgrade Location La Verne, CA Owner Metropolitan Water District of Southern California Project Manager Name Carl Allen (909) 392-2533 E-mail and Telephone No. callen@mwdh2o.com Contract Value $711, 098.64 (including change orders) $947,658.00 Brief Description of Firm's Scope of Install Electrical and Instrumentation for Water Treatment Facility Filtration Work for the Project and Chemical Treatment System Completion Date August 2014 Project No. 7 Project Name Orange Park Acres Well No 1 Wellhead Facility Location Orange, CA Owner Irvine Ranch Water District Jacob Moeder Project Manager Name (949) 453-5544 E-mail and Telephone No. Moeder@IRWD.com Contract Value $947,658.00 (including change orders) Brief Description of Firm's Scope of Install Electrical, Control, SCADA and Instrumentation for Water Treatment Work for the Project Well Wellhead & Chemical Treatment System Completion Date January 2015 3 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 ■ f•� LRCCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric,lnc. — Statement of Qualifications Project No. 8 Project Name Whittier Pumping Plant No. 2. Replacement Project Location City of Whittier Owner Whittier Utility Authority Project Manager Name Kieler Smith E-mail and Telephone No. (909) 892-8330 E-mail and Telephone No. kielersmith@mbakerintl.com Contract Value $2.061,773.00 (including change orders) $286,983.00 (including change orders) Potable water distribution system pump station and (12) Well Pump Sites, Brief Description of Firm's Scope of (2) On Site Reservoir Sites, (3) Off Site Reservoirs and Instrumentation, Work for the Project PLC's and SCADA System and Programing and the installation of all electrical Completion Date conduit and wiring for a 3,000AMP Switchgear and MCC. Completion Date November 2015 Project No. 9 ECLWRF RO Trains 1,2 & 3 Power Panels and RO Train 3 VFD Replacement Project Name Project Location City of EI Segundo Owner West Basin Municipal Water District Project Manager Name Rajen Budhia, P.E. E-mail and Telephone No. (310) 660-6241 rajenb@westbasin.org Contract Value $286,983.00 (including change orders) Brief Description of Firm's Scope of Install Electrical and Instrumentation for the water treatment facility, along Work for the Project with a new power panel and VFD and all electrical conduit and wiring. Completion Date November 2015 4 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 `.CCY ELECrRlc City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Project No. 10 Project Name Burris Pump Station Phase 2 Location Anaheim, CA Owner Orange County Water District Project Manager Name Ryan Bouley (714) 378-3200 E-mail and Telephone No. rbouley@ocwd.com Contract Value $ 2,501,583.50 (including change orders) $ 833,128.00 (including change orders) Electrical and Instrumentation for a new pump station. 4160V, 2000A New Brief Description of Firm's Scope of Service, QTY (4) 1750HP 4160 VFD's 2000A Motor Control Center Work for the Project Installation, Allen-Bradley PLC, HMI and SCADA Installation and installation Completion Date of a 12KV/4.2KV Transformer. Completion Date November 2017 Project No. 11 Project Name WRD Diversion Structures Location Pico Rivera, CA Owner Water Reclamation District of Southern California Jim McDavid, P.E. Project Manager Name (562) 921-5521 E-mail and Telephone No. jmcdavid@wrd.org Contract Value $ 833,128.00 (including change orders) Brief Description of Firm's Scope of Electrical and Instrumentation for a spreading grounds diversion structure Work for the Project Completion Date May 2016 - 4 5 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 I�CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Project No. 12 Project Name Regional Treatment Plant Cogeneration & Switchgear Upgrade Project Location Laguna Niguel, CA Owner South Orange County Wastewater Authority Project Manager Name Mike Matson & Brian Peck Project Manager Name (949) 234-5400 E-mail and Telephone No. mmatson@socwa.com & bpeck@socwa.com Contract Value $ 1,811,025.28 (including change orders) Furnish & Install 9 Miles of Fiber Optics, Power and Instrumentation Cable Work for the Project Demolition of existing conduit and wire, furnish and install underground Brief Description of Firm's Scope of conduit, manholes, 2,000FT of 12x750MCM XHHW Power Feeder Wire, Work for the Project Instrument Cable, Switchgear, Cogeneration Engine, PCL and SCADA Completion Date July 2018 Project No. 13 Project Name Dominguez Gap Barrier Telemetry Systems Location Los Angeles County Owner County of Los Angeles Department of Public Works Project Manager Name Adam Lee, P.E. (626)458-6185 E-mail and Telephone No. aw.lee@dpw.lacounty.gov Contract Value $ 2.1M (including change orders) $ 3,343,284.82 Brief Description of Firm's Scope of Furnish & Install 9 Miles of Fiber Optics, Power and Instrumentation Cable Work for the Project for SCADA and Telemetry System and Flow Diversion. Completion Date June 2018 Project No. 14 Project Name Mesa Well Automation & Rehabilitation Location Costa Mesa, CA Owner Mesa Water District Kieler Smith Project Manager Name (949) 330-4172 E-mail and Telephone No. kielersmith@mbakerintl.com Contract Value $ 3,343,284.82 (including change orders) 5 Well Sites, Integration & Automation, (4) Variable Frequency Drives, (5) Brief Description of Firm's Scope of Motor Control Centers, (5) Switchboards, Instrumentation at all Sites, Work for the Project Flowmeters, Control Panels at all Sites, Setting of a 164 Sq Ft Prefabricated Electrical Building at Well 1. Completion Date February 2019 61Section D LEED Electric Inc. Oct. 8, 2021 1=0016J ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Project No. 15 Project Name Temescal Canyon Park Stormwater BMP Project Phase II Location Los Angeles, CA Owner City of Los Angeles Depart. Of Public Works, Bureau of Engineering Project Manager Name Waleed Azar (213) 272-4254 E-mail and Telephone No. Waleed.azar@lacity.org Contract Value $ 659,143.00 (including change orders) $4,039,000.00 Brief Description of Firm's Scope of Installation of new conduit, wire, instrumentation and instrument cable. Work for the Project Furnish and Install VFD, MCC Switchgear, and new Stormwater Treatment System. Completion Date August 2018 Project No. 16 Project Name Advanced Water Treatment Demonstration Facility Location Carson, CA Owner Metropolitan Water District of Southern California Project Manager Name Joe Robles, P.E. E-mail and Telephone No. (909) 392-2586 JRobles@mwdh2o.com Contract Value $4,039,000.00 (including change orders) New Ground up Advanced Water Treatment Demonstration Facility with 0.5MGD Clean Water Production. Systems installed MSR, Chemical Feed Brief Description of Firm's Scope of System, RO System, Advanced Oxidization UV. Turn Key Electrical and Work for the Project Instrumentation which included Prefabricated Electrical Building, Service Switchboard, MCC, VFD's, Main PLC (1,500 1/0's), RTU, Local Control Panels, (11) Analyzer Racks, Ammonia, PLC & SCADA, Programming, Testing, Start- up & Commissioning. Completion Date December 2019 7 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 `CCU ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications Project No. 17 Project Name Hyperion Secondary Effluent Pump Station Improvements Location Playa Del Rey, CA Owner West Basin Municipal Water District Project Manager Name Kevin Cullen, MSCE E-mail and Telephone No. (310) 660-6259 E-mail and Telephone No. KevinC@westbasin.org Contract Value $3,080,000.00 (including change orders) $196,371.37 Brief Description of Firm's Scope of Furnish & Install Electrical Ductbank, Medium Voltage Switchgear, Control Work for the Project Panels, DCS System, Motor Control Center and Pumps, 4160V, Qty (2) 600A Work for the Project with Main -Tie -Main Circuit Breaker Completion Date January 2020 Project No. 18 Project Name Los Coyotes WRP Stage Two Process Air Compressor Motor Starting Equipment Location Cerritos, CA Owner County Sanitation Districts of Los Angeles County Project Manager Name Perry Palencia, P.E. E-mail and Telephone No. (562) 908-4288x5822 PPalencia@lacsd.org Contract Value $196,371.37 (including change orders) Brief Description of Firm's Scope of Furnish & Install MV 4160,1200A Switch, Terminate, Start -Up, Testing in Work for the Project Wastewater Treatment Facility Completion Date July 2018 8 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications Project No. 19 Project Name Venice Dual Force Main & Pumping Plant Generator Replacement Location Venice, CA Owner City of Los Angeles, Bureau of Engineering Richard Southerland Project Manager Name (310) 301-2109 E-mail and Telephone No. Richard.southerland@lacity.org Contract Value $4,688,790.00 (including change orders) Brief Description of Firm's Scope of Replacement of Generators, furnish and install Instrumentation and Work for the Project Controls, Underground conduits, wire, cable and controls. Work for the Project and Startup Services. Completion Date Jan. 2020 Project No. 20 Project Name Valencia Water Reclamation Plant UV Disinfection Facilities Location Valencia, CA Owner Santa Clarita Valley Sanitation District of Los Angeles County Jelmer Torres Project Manager Name (562) 699-7411 E-mail and Telephone No. jtorres@lacsd.org Contract Value $3,633,922.00 (including change orders) Furnish and install new UV Disinfection System, infrastructure, including 2 Brief Description of Firm's Scope of Unit Substations, MCC's VFD's, Control Panels, Instruments, Commissioning Work for the Project and Startup Services. Completion Date March 2021 9Section D LEED Electric Inc. Oct. 8, 2021 �.CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Project No. 21 Project Name Greg Avenue Pressure Control Structure Pump Modification and New Project Name Control Building Location Sun Valley, CA Owner The Metropolitan Water District of Southern California Project Manager Name Joe Robles, P.E., (909) 392-2586, JRobles@mwdh2o.com E-mail and Telephone No. Shane Singh, (303) 995-1287, shane.ramcharansingh@stantec.com Contract Value Zakir Hirani, (626) 375-6780, zakir.hirani@stantec.com Contract Value $3,539,258.00 (including change orders) Electrical and Instrumentation Maintenance for LA Counties Seawater Brief Description of Firm's Scope of New pump station building, infrastructure, including new LADWP Brief Description of Firm's Scope of Substation, MV Switchgear, MV VFD's, 4160V switchgear, 1,200AMP, Work for the Project temporary 4160V switchgear, bus duct, security system, control panels, flow meters, PLC and programming, commissioning, and startup. Completion Date Feb. 2021 Project No. 22 Seawater Barriers Maintenance Services for Telemetry System and Project Name Appurtenances 2015-2020 Location Los Angeles County, CA Owner County of Los Angeles Department of Public Works Project Manager Name Adam Lee, P.E. (626)458-6185 E-mail and Telephone No. awlee@dpw.lacounty.gov Contract Value $416,309.00 Annually (including change orders) Electrical and Instrumentation Maintenance for LA Counties Seawater Brief Description of Firm's Scope of Barrier Injection Wells and Observation Wells. Installation of sensors, instruments, conduit, wire, testing of instruments and equipment as well as Work for the Project water levels with sounder tool. Over 30 wells in the Long Beach, Wilmington, Carson area. Completion Date July 2020 10 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 ■ ��� IMMOLI ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Project No. 23 Project Name Valencia Water Reclamation Plant Advanced Water Treatment Facility Location Valencia, CA Owner Santa Clarita Valley Sanitation District of Los Angeles County Project Manager Name Irene Chang (562) 908-4288 ext. 5817 E-mail and Telephone No. ichang@lacsd.org Contract Value $11,279,000.00 (including change orders) Ground up 5.OMGD advanced water treatment facility, including installation of microfiltration equipment, nanofiltration equipment, and an enhanced membrane system consisting of reverse osmosis and other water treatment equipment; construction of a metal building, electrical and control room, Brief Description of Firm's Scope of electrical substation and transformers for a new power service, duct banks and electrical conduit, underground utilities, instrumentation and piping Work for the Project systems, fire prevention systems, above ground tanks, concrete wet wells, concrete slabs, truck loading station, pump stations, asphalt roads, chemical storage and cleaning systems, metal canopies, drainage systems, site improvements, testing, startup and commissioning of LEI supplied equipment. Completion Date Expected December 2021 11ISection D LEED Electric Inc. Oct. 8, 2021 ■ i>• � `CCU ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Client No.1 Client Name Irvine Ranch Water District Contact E-mail, Telephone No. Jacob Moeder 15600 Sand Canyon Ave and Address (949) 453-5544 Irvine, CA 92618 Moeder@IRWD.com Client No. 2 Client Name Metropolitan Water District of Southern California Contact E-mail, Telephone No. Carl Allen 700 Moreno Ave. and Address (909) 392-2533 La Verne, CA 91750 callen@mwdh2o.com Client No. 3 Client Name County of Los Angeles, Department of Public Works Contact E-mail, Telephone No. Adam Lee 900 S Fremont Ave and Address (626) 458-6185 Alhambra, CA 91803 AWLEE@dpw.lacounty.gov Client No. 4 Client Name Sanitation District of Los Angeles County Contact E-mail, Telephone No. Chris Larson 1955 Workman Mill Rd and Address (310) 736-8438 Whittier, CA 90601 CLarson@lacsd.org Client No. 5 Client Name City of Los Angeles, Department of Public Works Contact E-mail, Telephone No. John Hamilton 12000 Vista Del Mar and Address (310) 648-6129 Playa Del Rey, CA 90293 John.cobb.hamilton@lacity.org Client No. 6 Client Name Orange County Water District Contact E-mail, Telephone No. Ryan Bouley 18700 Ward Street, and Address (714) 378-3200 Fountain Valley, CA 92708 rbouley@ocwd.com 12 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 E City of Seal Beach lownsi RFP On -Call Electrical Maintenance and Repair Services ELECTRIC LEED Electric, Inc. — Statement of Qualifications Client No.'7 Client Name Mesa Water District Contact E-mail, Telephone No. Dustin Burnside 1965 Placentia Ave and Address (949) 207.5466 Costa Mesa, CA 92627 DustinB@MesaWater.org Client No. 8 Client Name City of Santa Monica Contact E-mail, Telephone No. Deborah McCloskey 2500 Michigan Avenue and Address (310) 458.2201 Santa Monica, CA 90404 Deborah. McCloskey@SMGOV. NET Client No. 9 Client Name Client Name Water Replenishment District (WRD) of Southern California Contact E-mail, Telephone No. Tom Knoell 4040 Paramount Blvd. and Address (562) 275.4266 Lakewood, CA 90712 Walnut, CA 91788-0489 tknoell@wrd.org Client No. 10 Client Name J.F. Shea Construction Contact E-mail, Telephone No. Ray Watford 667 Brea Canyon Road, Suite 30 y and Address (909) 595-4397 ray.watford@jfshea.com Walnut, CA 91788-0489 Client No. 11 Client Name Kiewit Infrastructure West Co. Contact E-mail, Telephone No. Danny Mckie (562) 946-1816 10704 Shoemaker Ave. and Address Danny.McKie@kiewit.com Santa Fe Springs, CA 90670 Client No. 12 Client Name Pacific Hydrotech Corporation Contact E-mail, Telephone No. Ozzie Garibaldo 314 E. 3rd St. and Address (951) 943-8803 Perris, CA 92570 ozzie@pachydro.com 131 Section D LEED Electric Inc. Oct. 8, 2021 ■ 1=11=1� IMMMU ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Client No. 13 Client Name RSH Construction Contact E-mail, Telephone No. Bob Hamilton 3883 Wentworth Drive and Address (951) 925-2288 Hemet, CA 92545 bhamilton@rshconstruction.com Client No. 14 Client Name Schuler Engineering Contact E-mail, Telephone No. Brian Sohl 564 Bateman Circle and Address (951) 738-9215 Corona, CA 92880 brian@schulerengineering.com Client No. 15 Client Name Olsson Construction Contact E-mail, Telephone No. Kris Olsson 326 W Katella Ave #4J and Address (714) 516-9496 Orange, CA 92867 kris@olssonconstruction.com Client No. 16 Client Name SS Mechanical Construction Corp. Contact E-mail, Telephone No. John Whelan 26561 Jacinto Drive and Address (714) 847-1317 Mission Viejo, CA 92692 John@ssmechanical.com Client No. 17 Client Name Cora Constructors Contact E-mail, Telephone No. Karen Lowe 75140 St Charles PL # A and Address (760) 779-9459 Palm Desert, CA 92211 karen@coraconstructors.com Client No. 18 Client Name PPC Construction, Inc. Contact E-mail, Telephone No. Samuel P. Hannah 930 Colorado Blvd., Suite 3 and Address (323) 256-2600 Los Angeles, CA 90041 samuel.hannah@ppcco.net 141 Section D LEED Electric Inc. Oct. 8, 2021 ■ ��� I.CCY ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications 'Client No. 19 Client Name City of Santa Ana Contact E-mail, Telephone No. Juan Ramirez 220 S. Daisy Ave and Address (714) 647.3377 Santa Ana, CA 92703 jramirez@santa-ana.org 15 1 S e c t i o n D LEED Electric Inc. Oct. 8, 2021 Ln■ ��� I.CCY ELECTRIC E. List of Subcontractors City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Subcontractors will be approved prior to use in this maintenance and repair service contract. Some of those subcontractors that we utilize are: 1. SOFIA Electric, Inc. — Instrumentation and Controls 2. Premier Cabling Solutions — Fiber Optic 3. Johnson Controls — Fire Alarm 4. Hal Hays Construction — Excavation, Trenching, Civil, Backfill 5. 316 Engineering and Construction Co. Inc. — Excavation, Trenching, Civil, Backfill 6. TBD — To be proposed as necessary based on the scope of services, if necessary. 1 S e c t i o n E Leed Electric Inc. Oct. 8, 2021 IdAl. !!fie CONTRACTORS STATE LICENSE BOAR; ®Contractor's License Detail for License # 291825 DISCLAIMER: A license status check provides information taken from the CSLB license database. Before relying on this information, you should be aware of the following limitations. CSLBcomplaint disclosure isrestricted bylaw (6&P 71246) If this entity is subject to public complaint disclosure click on link that will appear below for more information. Click here for a definition of disclosable actions. only construction related civil judgments reported to CSLB are disclosed (B&P 7071.17). Arbitrations are not listed unless the contractor fails to comply with the terms, Due to workload, there maybe relevant information that has not yet been entered into the board's license database. Data current as of 11/4/202110:03:28 AM SOFFA ELECTRIC INC 5901 CORVETTE STREET COMMERCE, CA 90040 Business Phone.Number:(323) 728-0230 Entity Corporation Issue Date 03/15/1974 Reissue Date 07/06/2018 Expire Date 07/31/2022 This license is current and active. All information below should be reviewed. 910 - ELECTRICAL F Contractor's Bond This license riled a Contractor's Bond with SURETEC INSURANCE COMPANY. Bond Number: 139261 Bond Amount: $15,000 Effective Date: 07/01/2020 Contractor's Bond History ____ _ ___ Bond 'ofQualifying Individual This license filed Bond of Qualifying Individual number 139263 for SALIB MORCOS MANSOUR in then amount of $12,500 with SURETEC INSURANCE COMPANY. ........... ............ ..... ....... __.._._........................... Effective Date: 07/01/2020 BQI's,Bon N, tory• This license has workers compensation insurance with the SENTINEL INSURANCE COMPANY LTD .........._....__......_.__......................................_..___._._._ Policy Number:72WECAJ8HNU Effective Date: 02/01/2021 Expire Date: 02/01/2022 Workers' Compensation History Copyright © 2021 State of California Firefox Contractor Information Legal Entity Name SOFFA ELECTRIC, INC. Legal Entity Type Corporation Status Active Registration Number PW -LR -1000414922 Registration effective date 7/1/2020 Registration expiration date 6/30/2022 Mailing Address 5901 Corvette St. Commerce 90040 CA United 5... Physical Address 5901 Corvette St. Commerce 90040 CA United 5... Email Address Trade Name/DBA License Number(s) CSLB:291825 Legal Entity Information Corporation Number: Federal Employment Identification Number: President Name: Mahnaz Hemmat Vice President Name: Danny Banez Treasurer Name: Maya Mahmoudi Secretary Name: Anahita Mahmoudi CEO Name: Mahnaz Hemmat Agent of Service Name: Desi Rose Agent of Service Mailing Address: 5901 Corvette St. Commerce 90040 CA United States of America Workers Compensation https://cadir.secure.force.com/ContractorSearch/PrintRegDetails Registration History Effective Date Expiration Date 7/1/2019 7/1/2020 6/30/2020 6/30/2022 1 of 2 11/4/2021, 10:14 AM Firefox https://cadirsecure.force.com/ContractorSearch/PrintRegDetails Do you lease employees No through Professional Employer Organization (PEO)?: Please provide your current workers compensation insurance information below: PEO InformationPEO PEO PEO Name Phone Email Insured by Carrier Policy Holder Name:Soffa Electric, Inc.Insurance Carrier:Preferred Employers Policy Number:WKN168538-1Inception date:2/1/2020Expiration Date:2/1/2021 2 of 2 11/4/2021, 10:14 AM I&I 0 CONTRACTORS STATE LICENSE BOAR! • �o OContractor's License Detail for License # 841941 DISCLAIMER: A license status check provides information taken from the CSLB license database. Before relying on this information, you should be aware of the following limitations. CSLB complaint disclosure isrestricted bylaw (B&P712a;6) If this entity is subject to public complaint disclosure click on link that will appear below for more information. Click here for a definition of disclosable actions. P Only construction related civil judgments reported to CSLB are disclosed(MRIQ71.17). Arbitrations are not listed unless the contractor fails to comply with the terms. Due to workload, there maybe relevant information that has not yet been entered into the board's license database. Data current as of 11/4/202110:04:24 AM PREMIER CABLING SOLUTIONS 3070 WEST MAIN STREET ALHAMBRA, CA 91801 Business Phone Number:(626) 768-1050 Entity Corporation Issue Date 06/30/2004 Reissue Date 11/04/2008 Expire Date 11/30/2022 This license is current and active. All information below should be reviewed. ► C-7 -LOW VOLTAGE SYSTEMS ► C10 -ELECTRICAL Contractor's Bond This license filed a Contractor's Bond with CONTRACTORS BONDING AND INSURANCE COMPANY. ......................................_.__......._._..._.....................I........._.... - -._.. Bond Number: CF2871 Bond Amount: $15,000 Effective Date: 01/01/2016 Contractor's Bond History, �— Bond of Qualifying Individual The qualifying individual ARAM EUGENE LEWIS certified that he/she owns 10 percent or more ofthe voting stock/membership interest of this company; therefore, the Bond of Qualifying Individual isnot required. Effective Date: 11/04/2008 This license has workers compensation insurance with the STATE COMPENSATION INSURANCE .............................. -__._.._.._...__......................_.._......_ FUND Policy Number:9124075 Effective Date: 02/01/2015 Expire Date: 02/01/2022 Workers' Compensation Histpry, P. 11/04/2008 -LICENSE REISSUED TO ANOTHER ENTITY Copyright © 2021 State of California Firefox Contractor Information Legal Entity Name Premier Cabling Solutions, Inc. Legal Entity Type Corporation Status Active Registration Number 1000009653 Registration effective date 8/10/2020 Registration expiration date 6/30/2022 Mailing Address 3070 W. Main St. Alhambra 91801 CA United St... Physical Address 3070 W. Main St. Alhambra 91801 CA United St... Email Address Trade Name/DBA License Number(s) CSLB:841941 Legal Entity Information Corporation Number: Federal Employment Identification Number: President Name: Aram Lewis Vice President Name: Aram Lewis Treasurer Name: Aram Lewi Secretary Name: Aram Lewis CEO Name: Aram Lewis Agent of Service Name: Aram Lewis Agent of Service Mailing Address: 3070 W. Main St. Alhambra 91801 CA United States of America Workers Compensation 1 of 2 https://cadir.secure.force.com/ContractorSearch/PrintRegDetails Registration History Effective Date Expiration Date 7/18/2018 6/30/2019 10/11/2017 6/30/2018 6/9/2016 6/30/2017 7/22/2015 6/30/2016 2/13/2015 6/30/2015 7/1/2019 6/30/2020 8/10/2020 6/30/2022 11/4/2021, 10:15 AM Firefox https://cadir.secure.force.com/ContractorSearch/PrintRegDetails Do you lease employees No through Professional Employer Organization (PEO)?: Please provide your current workers compensation insurance information below: PEOInformationPEO PEO PEO Name Phone Email Insured by Carrier Policy Holder Name:Premier Cabling SolutionsInsurance Carrier:State Fund Policy Number:9124075-20Inception date:2/1/2020Expiration Date:2/1/2021 2 of 2 11/4/2021, 10:15 AM Jimmy Martinez I Fire Construction Sales Johnson Controls Inc. Southern California Mobile: (562) 321-0429 Jaime.l.Martinez@JCI.com /www.JohnsonControls.com A& PM CONTRACTORS STATE LICENSE BOAR; M. OContractor's License Detail for License # 986047 DISCLAIMER: A license status check provides information taken from the CSLB license database. Before relying on this information, you should be aware of the following limitations. C5LB complaint disclosure is restricted by law @?jR 7124 6) If this entity is subject o publiccomplaint disclosure click on link that will appear below for more information. Click here for a definition of disclosable actions. o only construction related civil judgments reported to CSLB are disclosed 7071.17). P Arbitrations are not listed unless the contractor fails to comply with the terms. Due to workload, there maybe relevant information that has not yet been entered into the board's license database. Data current as of 11/4/202110:05:38 AM JOHNSON CONTROLS FIRE PROTECTION LP P O BOX 3042 BOCA RATON, FL 33431 Business Phone Number:(562) 405-3800 Entity Partnership Issue Date 08/14/2013 Expire Date 08/31/2023 This license is current and active. All information below should be reviewed. ► C10 -ELECTRICAL I. C16 - FIRE PROTECTION i Contractor's Bond. . This license filed a Contractor's Bond with FEDERAL INSURANCE COMPANY. .................................... __-- .......... _.._... ............ Bond Number: 82332032 Bond Amount: $15,000 Effective Date: 01/01/2016 Contractor's Bond History Bond of QuaUfying Individual ► This license filed Bond of Qualifying Individual number 82332031 for RONALD GILBERT MAYLE in the amount of $12,500 with FEDERAL INSURANCE COMPANY. .............................. ------------- —•-............ Effective Date: 08/13/2013 ► This license filed Bond of Qualifying Individual number K40505179 for TIMOTHY JOHN ROACH in the amount of $12,500 with FEDERAL INSURANCE COMPANY,. Effective Date: 04/15/2020 Workers' Compensation This license has workers compensation insurance with the OLD REPUBLIC INSURANCE COMPANY Policy Number:MWC313943 Effective Date: 10/01/2018 Expire Date: 10/01/2022 Workers' Com,Pensation _H 15iory Other ► Personnel listed on this license (current or disassociated) are listed on other licenses. Copyright © 2021 State of California Firefox Contractor Information Legal Entity Name JOHNSON CONTROLS, INC Legal Entity Type Corporation Status Active Registration Number 1000000593 Registration effective date 7/1/2021 Registration expiration date 6/30/2024 Mailing Address 103 WOODMERE ROAD, SUITE 110 FOLSOM 95630 C... Physical Address 103 WOODMERE ROAD, SUITE 110 FOLSOM 95630 C... Email Address Trade Name/DBA JOHNSON CONTROLS, INC License Number(s) CSLB:22445 CSLB:22445 1 of 3 https://cadir.secure.force.com/ContractorSearch/PrintRegDetails Registration History Effective Date Expiration Date 6/4/2018 6/30/2019 5/15/2017 6/30/2018 5/27/2016 6/30/2017 6/9/2015 6/30/2016 7/25/2014 6/30/2015 7/1/2019 6/30/2020 7/1/2020 6/30/2021 7/1/2021 6/30/2024 9 11/4/2021,10:17 Firefox https://cadir.secure.force.com/ContractorSearch/PrintRegDetails Legal Entity Information Corporation Number: 39-0380010 Federal Employment Identification Number: President Name: GEORGE OLIVER Vice President Name: JEFF WILLIAMS Treasurer Name: Marc Vandiepenbeeck Secretary Name: JOHN DONOFRIO CEO Name: GEORGE OLIVER Agent of Service Name: ERIK BECK Agent of Service Mailing Address: 103 WOODMERE ROAD SUITE 110 FOLSOM 95630 CA United States of America Agent of Service Name: Teresa Dolmseth Agent of Service Mailing Address: 103 Woodmere Road Suite 110 Folsom 95630 CA United States of America Agent of Service Name: WILLIAM LANGTRY Agent of Service Mailing Address: 103 WOODMERE ROAD, SUITE 110 FOLSOM 95630 CA United States of America Workers Compensation Do you lease employees No through Professional Employer Organization (PEO)?: Please provide your current workers compensation insurance information below: PEO InformationPEO PEO PEO Name Phone Email Insured by Carrier 2 of 3 11/4/2021, 10:17 AM Firefox https://cadir.secure.force.com/ContractorSearch/PrintRegDetaiIs Policy Holder Name:JOHNSON CONTROLS, INCInsurance Carrier: OLD REPUBLIC INSURANCE COMPANYPolicy Number:24147Inception date:10/2/2019 Expiration Date:10/1/2020 3 of 3 11/4/2021, 10:17 AM C ,& U.M. CONTRACTORS STATE LICENSE BOARI r OContractor's License Detail for License # 667560 DISCLAIMER: A license status check provides information taken from the CSLB license database. Before relying an this information, you should be aware of the following limitations. ► CSLScomplaint disclosure isrestricted bylaw (B&P 71246) If this entity is subject to public complaint disclosure click on link that will appear below for more information. Click here for a definition of disclosable actions. ► Onlyconstruction related civil judgments reported to CSLB are disclosed(B&P 7071,17). ► Arbitrations are not listed unless the contractor failstocomply with the terms. Due to workload, there maybe relevant information that has not yet been entered Into the board's license database. Data current as of 11/4/202110:08:23 AM HAL HAYS CONSTRUCTION INC 4181 LATHAM ST RIVERSIDE, CA 92501 Business Phone Number:(951) 788-0703 Entity Corporation Issue Date 03/19/1993 Reissue Date 11/20/2003 Expire Date 11/30/2023 This license is current and active. All information below should be reviewed. ► A -GENERAL ENGINEERING ► C12 -EARTHWORK AND PAVING ► C21.-_BUILDING,MOVING,DEMOLITION ► B -GENERAL BUILDING ECertifications ► HAZ-HAZARDOUSSUBSTANCESREMOVAL !_ Contmdor'sBond. This license filed a Contractor's Bond with AMERICAN CONTRACTORS INDEMNITY COMPANY. ................._.___......._..___.._......................._..........._.._•-.____..._.. -• Bond Number: SC6057594 Bond Amount: $15,000 Effective Date: 01/01/2016 Contractor's Bond History ..... I Bondof'Qualifying individual ► The qualifying individual HAL ARTHUR HAYS certified that he/she owns 10 percent or more of the voting stock/membership interest of this company; therefore, the Bond of Qualifying Individual is notrequired. Effective Date: 04/02/2008 BQI's,Band History, ► This license filed Bond of Qualifying Individual number 100328447 for KIRBY SCOTT HAYS in the amount of $12,500 with AMERICAN CONTRACTORS INDEMNITY COMPANY. _......................._.......... _._.____ ...__... Effective Date: 10/19/2016 This license has workers compensation insurance with the FEDERAL INSURANCE COMPANY ____-__.............._........._..___ _._.. ___...... Policy Number:54309830 Effective Date: 11/01/2018 Expire Date: 11/01/2022 Workers' Compensation History ► 11/20/2003 -LICENSE REISSUED TO ANOTHER ENTITY ► Personnel listed on this license (current or disassociated) are listed on other licenses. Copyright © 2021 State of California Firefox Contractor Information Legal Entity Name HAL HAYS CONSTRUCTION, INC. Legal Entity Type Corporation Status Active Registration Number 1000005009 Registration effective date 7/1/2021 Registration expiration date 6/30/2022 Mailing Address 4181 LATHAM STREET RIVERSIDE 92501 CA Uni... Physical Address 4181 LATHAM STREET RIVERSIDE 92501 CA Uni... Email Address Trade Name/DBA License Number(s) CSLB:667560 CSLB:667560 Legal Entity Information Corporation Number: C2453073 Federal Employment Identification Number: President Name: KIRBY HAYS Vice President Name: HAL HAYS Treasurer Name: HAL HAYS Secretary Name: HAL HAYS CEO Name: KIRBY HAYS Agent of Service Name: KIRBY HAYS Agent of Service Mailing Address: 4181 LATHAM STREET RIVERSIDE 92501 CA United States of America https:Hcadir.secure.force.com/ContractorSearch/PrintRegDetails Registration History Effective Date Expiration Date 6/26/2018 6/30/2019 5/31/2017 6/30/2018 6/7/2016 6/30/2017 7/6/2015 6/30/2016 1/8/2015 6/30/2015 10/23/2019 6/30/2020 8/3/2020 6/30/2021 7/1/2021 6/30/2022 1 of 2 11/4/2021, 10:18 AM Firefox https://cadir.secure.force.com/ContractorSearch/PrintRegDetails Workers Compensation Do you lease employees No through Professional Employer Organization (PEO)?: Please provide your current workers compensation insurance information below: PEO InformationPEO PEO PEO Name Phone Email Insured by Carrier Policy Holder Name:HAL HAYS CONSTRUCTION, INC.Insurance Carrier: FEDERAL INSURANCE COMPANYPolicy Number:54309830Inception date:11/1/2020 Expiration Date:11/1/2021 2 of 2 11/4/2021, 10:18 AM .Ad&► �P' CONTRACTORS STATE LICENSE BOARi OContractor's License Detail for License # 986498 DISCLAIMER: A license status check provides information taken from the CSLB license database. Before relying on this information, you should be aware of the following limitations. ► CSLB complaint disclosure isrestricted bylaw (B&P712a;6) If this entity is subject to public complaint disclosure click on link that will appear below for more information. Click here for a definition of disclosable actions. only construction related civil judgments reported to CSLB are disclosed (Q 707117). o Arbitrations are not listed unless the contractor fails to comply with the terms. ► Due to workload, there may be relevant information that has not yet been entered into the board's license database. Data current as of 11/4/202111:08:12 AM 316 ENGINEERING AND CONSTRUCTION CO INC 7434 GARVALIA AVENUE ROSEMEAD, CA 91770 Business Phone Number:(818) 395-7989 Entity Corporation Issue Date 09/04/2013 Expire Date 09/30/2023 This license is current and active. All information below should be reviewed. ► A-GENERALENGINEERING ► B-GENERALBUILDING ► C34 -PIPELINE Contractor's: Bond This license filed a'Contractor's Bond with NORTH_ RIVER, INSURANCE COMPANY (THE). Bond Number: 04CF602344 Bond Amount: $15,000 Effective Date: 09/30/2021 Contractor's Bond History, Bond of Qualifying individual --j The qualifying individual JOHN WILLIAM MASSIE certified that he/she owns 10 percent or more of the voting stock/membership interest of this company; therefore, the Bond of Qualifying Individual is not required. Effective Date: 09/29/2020 BQI's_Bond History. This license has workers compensation insurance with the INSURANCE COMPANY OF THE WEST ........... _..__._.._..__.................................................._ Policy Number:WTX5060064 Effective Date: 03/27/2021 Expire Date: 03/27/2022 Workers' Compensation History ► Personnel listed on this license (current or disassociated) are listed on other licenses. Copyright ©,2021 State of California Firefox Contractor Information Legal Entity Name 316 ENGINEERING & CONSTRUCTION INC Legal Entity Type Corporation Status Active Registration Number 1000006807 Registration effective date 10/3/2019 Registration expiration date 6/30/2022 Mailing Address 7434 GARVALIA AVE ROSEMEAD 91770 CA Unit... Physical Address 7434 GARVALIA AVE ROSEMEAD 91770 CA Unit... Email Address Trade Name/DBA 316 ENGINEERING & CONSTRUCTION INC License Number(s) CSLB:986498 CSLB:986498 Legal Entity Information Corporation Number: Federal Employment Identification Number: President Name: JOHN MASSIE Vice President Name: Treasurer Name: Secretary Name: KAREN MASSIE CEO Name: Agent of Service Name: JOHN MASSIE Agent of Service Mailing Address: 7434 GARVALIA AVE ROSEMEAD 91770 CA United States of America Workers Compensation Do you lease employees No https:Hcadir.secure.force.com/ContractorSearch/PrintRegDetails Registration History Effective Date Expiration Date 6/14/2018 6/30/2019 5/9/2017 6/30/2018 6/16/2016 6/30/2017 8/17/2015 6/30/2016 1/27/2015 10/3/2019 6/30/2015 6/30/2022 1 of 2 11/4/2021, 11:09 AM Firefox https://cadir.secure.force.com/ContractorSearch/PrintRegDetails through Professional Employer Organization WEO �• a a provide your current workers compensation insurance information below: PEO InformationPEO PEO PEO Name Phone Email Insured by Carrier Policy Holder Name:316 ENGINEERING & CONSTRUCTION INCInsurance Carrier: STATE COMPENSATION INSURANCE FUNDPolicy Number:9093860-19Inception date: 3/27/2018Expiration Date:3/27/2020 2 of 2 11/4/2021, 11:09 AM ■ !�� `CCU ELECTRIC F. Sample Letter Proposal Attached. City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications 11 S e c t i o n F Leed Electric Inc. Oct. 8, 2021 13138 ARCTIC CIRCLE LEED ELECTRIC INC. SANTA FE SPRINGS, CA 90670 DIR REG. NO. 1000004633 EXP. 6/30/22 Power, Control and Instrumentation Contractor Since 1979 CA License# 379096 C-10 EXP. 7/31/23 LS MEMBER OF THE NATIONAL ELECTRICAL CONTRACTORS ASSOCIATION Dep. of General Services SB -PW# 36862 TO: Bidding Contractors ATTN: Estimator EST. NO.: 21OXX Bid Date/Time: X/XX/2021 2:OOPM Date: 10/8/2021 REFERENCE: PROJECT NAME Leed Electric Inc. is pleased to submit the following Electrical proposal for the above -referenced project per Plans and Soecifications or Site Walk outlined below: ❖ SPECIFICATIONS SECTIONS: ❖ DRAWING SHEETS: ❖ ADDENDUM: ' i \ 01 Work Scope: `r% ■ Electrical safe Demo and demo of cabling (Removal of conduit and equipment by othePs), ■ Furnish and install conduit and wiring shown on electrical drawings Sheets E=001 thru 902:. 'N)' ■ Furnish and install cable tray system as shown Sheets E-052 & E-503. ■ Furnish and install Duct Banks per Duct Bank Sections Sheets E-854 Thru E-855 including= precast concrete pull boxes, (INCLUDING 316SS CUSTOM DIVIDERS SPEC. F16130 -2.06-F) ;PlarisSheet E-007 Items 62 thru 69. Furnish and install concrete encasement for new Electrical duct banks (Excavalion and Backfill by Others). ■ Furnish and install grounding per grounding plans Sheets E056; E-507;, E-508. ■ Furnish and install Fire alarm System, Security System, and Cathodic Protection System per Plans and Specs. ■ Furnish and install all Lighting and Lighting Control System per plans�SheetsE-120 thru E-133. ■ Furnish and Install Electrical switchgear per Switchgear drawings Sheets E-008 thru E-033. i.■ Furnish and Install Liebert UPS Systems and equipmerit per plans Sheet. ■ Furnish and install Instrumentation and ControlSystem per plans and -specifications. ■ Final Termination to Contractor Furnished'Generator and Generator Switchgear specified to be furnished by others. ■ Final Termination to Contractor Furnished Equipment including Electric Motors, Control Panel and Instrumentation specified to be furnished by others. ■ Final Termination to Owner Furnished Equipment including (15) (UV) Disinfection Reactors, (15) Unit Control Panels (UCP) and one Master Control,.Pariel (MCP). '' ■ Project commissioning assistance for period of 90 days of continuous operation including at least one electrician and instrument mechanic available within-an.l o6r of request to support the testing, startup, and commissioning of the facility throughout the'�duration. ■ Power Studies, NETA Testing Seismicanchorage calculation, Product Submittals, Loop drawings, Loop check, Startup, Testing, As=built, Warranty, Spare Parts and Training for Leed Electric Furnished Equipment. ■ This proposal is based,on field manpower by the International Brotherhood of Electrical Workers Local 441. 02 Exclusions: a. Demolition other. tharr-safe-off and pulling out wire. b. Bollards,,concrete pads; coring, patching, pole bases, welding, grout, drypack, blockouts or formed concrete. c. _.:Undergroundconduit trench excavation, pull box or manhole excavation, trench excavation of any kind, backfill, saw cutting; auguring, patching, concrete encasement, rebar reinforcement, concrete form work, shoring, trench plates,..traff, is control, sand bedding, crushed rock, surveying, and boring (Approx.1720ft Long X min 2ft Wide X min-3ft Deep,Trench for Cathodic Protection E-900) (Approx. 1,400ft Long X 2ft Wide X 3ft Deep Trench for Fiber Optics Conduit) and (Approx.1,300ft X 4ft Wide 3ft Deep Trench for Duct Banks) d. Additionalencasement concrete due to larger excavation (will be billed T&M). e. Concrete Cable Trench Sheet E-850 Section A -A, E-860, and E-811. f. Furnish and install raceway and wiring not shown on conduit and cable schedule unless otherwise specifically noted on scope of work. g. Furnish and install raceway and wiring between panels and instruments within package vendor skids. h. AC Induction Motor Electrical Testing. i. X-ray or detection services for exiting conditions. Rod Dean Phone: (562) 270-9500 Fax: (562) 863-5723 Email: Estimating@leedelectric.com Estimating Manager Direct: (562) 270-9501 Mobile: (562) 307-0344 Page 1 of 2 13138 ARCTIC CIRCLE ,LEED ELECTRIC INC. SANTA FE SPRINGS, CA 90670 LS DIR REG. NO. 1000004633 EXP. 6/30/22 Power, Control and Instrumentation Contractor Since 1979 CA License# 379096 C-10 EXP. 7/31/23 MEMBER OF THE NATIONAL ELECTRICAL CONTRACTORS ASSOCIATION Dep. of General Services SB -PW #36862 j. Installation of process instruments and floats. k. Grounding unless shown on drawings. I. Repairs of existing raceways unless specially noted on scope of work. m. Seismic calculations, Loop Drawing and Electrical NETA Testing for equipment not supplied by LEED. n. Fiber Optic Cable and Terminations unless otherwise specifically noted on scope of work. o. Furnishing Generator, Remote Annunciator and Generator Switchboard Specifications Section F16230. p. Door Card Readers (By Door and Hardware Manufacturer Sheet E-494 thru E-498). q. Slide Gate Operators, Controllers, Traffic Loops, Key Pads and Operators (Include power to gate`controllers). r. Pump Control Panels as furnished by Pump Manufacturers Spec. Sections F11140 and, F1.5440. ; s. Irrigation System and Controllers (Includes power to irrigation controllers). ' t. Specifications Section F11 Equipment and its Controls Panels and associated instiuments`(Vendor.Furnished). u. Specifications Section F15 Mechanical and its Control Panels and associated instruments (Vendor`Furnished). v. Specification Section 13425 Furnish Flow Meters (Indicated as optional adder)` w. Temporary Power, Temporary Generator, Generator Fuel, Temporary Phone Linesand-Temporary Lighting. x. Motors, Pumps, Fans, Sunshades, Valves, Isolation Valves, Valve Actuators, Mechanical Tubing, Mechanical in - Line devices, MOV's, Solenoid Valves, Ball Valves, Butterfly Valves, - Gate Valves and Valves_of any other kind. y. Special inspection, Welding, Scaffolding and/or platforms, Dewatering,;P.ainting, Fire Stopping, Asbestos or Lead abatement, Trach Containers, Onsite Parking Fees, Premium Time due io'del'is.cau6ed by other trades. z. Any mechanical HVAC equipment, Duct Detectors, CU, Mechanical 'C_ontrols, Temp. -Switches, and Exhaust Fans. aa. Permit fees, Inspection Fees, Bonding Premiums, and Utility Company Charges. 03 Qualifications: ■ We assume that we will be provided sufficient space o'n,==site forstorage containers and lay -down requirements. ■ Bid price is based on negotiation of mutually.agreeable contract language. ■ This cost proposal pricing is based on "Total,Bid'ltei4' and`i of per individual bid items or unit prices that are solely provided for progress invoicing purpose. ` ■ LEED is not liable for delays, material shortagelor cost increases due to COVID 19 or any other global pandemic. ■ Our bid is based on construction,time of XX calendar days from NTP, on a five day per week, eight hour per day schedule, and is further contingent on preceding trades completing their work in a timely manner consistent with the original schedule. Pricing is firm,for'1:4 days from the date of this bid unless noted otherwise herein. 04 Cost Proposal: Bid Item Description Total Cost #XX :`` $ TBD #XX $ TBD TOTAL BID ITEMS:. $ TBD Optional Adders:'- 1'Install Ultrasoriic,Flowmeter Sensors: $ PRICE TO FOLLOW 2:.., Furnish QTY'(1)144" Ultrasonic Flowmeter: $ PRICE TO FOLLOW 3. Fumish•QTY•(15) 48" Electromagnetic Flowmeters: $ PRICE TO FOLLOW \ Rod Dean Phone: (562) 270-9500 Fax: (562) 863-5723 Email: Estimating@leedelectric.com Estimating Manager Direct: (562) 270-9501 Mobile: (562) 307-0344 Page 2 of 2 ■ —�� `CCY ELECTRIC ATTACHED. r. 11 Section G City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Leed Electric Inc. Oct. 8, 2021 f FEE & COST PROPOSAL FOR ON-CALL ELECTRICAL MAINTENANCE AND REPAIR SERVICES (additional labor/equipment/material rates may be added/clarified with a separate attachment) MOBILIZATION COST (Normal Working Hours) 0% of Total Cost /TASK ORDER MOBILIZATION COST (Non -Working Hours) 0% of Total Cost /TASK ORDER MINIMUM CALL OUT (in dollars orhours, if applicable) 4 Hours LABOR NO. DESCRIPTION STANDARD OVERTIME DOUBLE TIME Ll Electrician $121.93 $ 165.40 $ 208.90 L2 Journeyman $103.61 $ 138.33 $173.06 L3 Helper/Apprentice (non -Journeyman) $81.59 $ 107.65 $ 133.69 L4 Superintendent $145.15 $196.90 $248.69 LS L6 L7 17 EQUIPMENT NO. DESCRIPTION UNIT PRICE E1 Pick up Truck $ 28.46 / HR E2 Bending/Threading Trailer $14.56 / HR E3 Power Generator (Under 10KW) $ 4.66 / HR E4 Forklift $ 500.00 / Week E5 Gradall $950.00 / Week MARK-UP FOR ITEMS NOT NOTED ABOVE NO. DESCRIPTION PERCENTAGE M1 Material 15% M2 Equipment 15 % M3 Labor 20% ADJUSTMENTS Provide any anticipated rate/cost adjustments as a separate attachment, if necessary. 18 ■ �I�>_ RP® ELECTRIC CYINUo 1 VDAVIONLY ELECTRIC INC. 13138 Arctic Circle Santa Fe Springs, CA 90670 TEL: (562) 270-9500 www.leedelectric.com Project: On -Call Electrical Maintenance & Repair LEI CE# TEXXXXX-XXX DATE: XX/XX/XXXX Contract: TXX-XXX RFI # LOCAL: 11 Customer: City of Seal Beach CD/DOC # ESTIMATOR: AS Description of -SAMPLE- Work: 1. Material 1. Material (See attached detail sheet) $ 2 . Quoted Material & Services (See attached vendor quotes) $ 3. Allowance Miscellaneous Material/Consumables/Small Tools 0.00% of Line 1 &2 $ 4. Subtotal: $ 5 . Sales Tax at applicable rate 10.50% of Line 4 $ 6. Shipping and Handling $ 7. Total Material Cost: $ II. Field Labor Regular Time Over Time x1.5 Over Time x2.0 8a . Electrician Labor Man Hours (see attached detail sheet) 0.00 hrs 0.00 hrs 0.00 hrs 8b. Job Factor 0.00 hrs 0.00 hrs 0.00 hrs 8c . Electrician Labor Efficiency Factor 0.00 hrs 0.00 hrs 0.00 hrs 8d . Safety 0.00 hrs 0.00 hrs 0.00 hrs Be. Clean-up 0.00 hrs 0.00 hrs 0.00 hrs 8f. As -Built Drawings 0.00 hrs 0.00 hrs 0.00 hrs 8g. TOTAL ESTIMATED DIRECT LABOR MH (8a thru 8f) 0.00 hrs 0.00 hrs 0.00 hrs 9. Journeyman hours (from 8g above -Regular Time) 0.00 hrs @ $103.61 /hour $ 9a . Journeyman hours (from 8g above -OT 1.5x) 0.00 hrs @ $138.33 /hour $ 9b. Journeyman hours (from 8g above -OT 2.0x) 0.00 hrs @ $173.06 /hour $ 10. Electrician GF/FM (Regular Time) 0.00 hrs @ $121.93 /hour $ - 10a . Electrician GF/FM (Over Time 1.5x) 0.00 hrs @ $165.40 /hour $ 10b. Electrician GF/FM (Over Time 2.0x) 0.00 hrs @ $208.90 /hour $ - 11. Helper/Apprentice (Regular Time) 0.00 hrs @ $81.59 /hour $ 12a . Helper/Apprentice (Over Time 1.5x) 0.00 hrs @ $107.65 /hour $ 12b. Helper/Apprentice (Over Time 2.0x) 0.00 hrs @ $133.69 /hour $ 13 . Total Direct Labor 9 thru 12 0.00 $ 14. Allowance Miscellaneous Material/Consumables/Small Tools 0.00% $ 15 .Overtime Expense from attached Schedule if applicable. 16. TOTAL LABOR COST: $ 111. DIRECT JOB EXPENSE 17. Truck w/tools 0.00 hrs @ $28.46 /hour $ 18. Bending/Threading Trailer 0.00 hrs @ $14.56 /hour $ 19. Power Generator (under 10KW) 0.00 hrs @ $4.66 /hour $ 20 . Forklift 0.00 hrs @ $500.00 /Week $ 21 . Gradall 0.00 hrs @ $950.00 /Week $ 22 . Project Manager/Design Consult/Fabrication 0.00 hrs @ $125.00 /hour $ 23 . Make Copies of Prints $0.00 $ 24. Rented/Owned Tools & Equipment (See attached Equipment list) $ 25. Allowance Miscellaneous Material/Consumables/Small Tools 0.00% $ 26. TOTAL EXPENSES: $ IV. OVERHEAD AND PROFIT 27. Material $ 28. Material Markup 15.0% of line 27 $ 29 . Field Labor $ 30 . Field Labor Markup 20.0% of line 29 $ 31 . Direct Job Expense $ - 32 . Direct Job Expense Markup 15.0% of line 31, $ 33 . Subcontract (See attached subcontractor quotes) $ 34. Subcontract markup 15.0% of line 33 $ 35 . Totals of Line 27 through 34 $ 36 . Extended Overhead Breakdown (see attached Breakdown sheet) $ 37 . Inefficiency Costs (see attached worksheet) $ 38 . Subtotal $ 39. Bond Adder 0.00% of line 38 $ 40. TOTAL FOR THIS ESTIMATE V. EXTENSION OF TIME REQUIRED: X 1 9 RA, f NuNca' h- .ricTngrfs7vaR of rr I41caJeWar(dayN AV% a 9 9 i / I Un■ ��� MCCI./ ELECTRIC H. Exceptions None at this time. City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEER Electric, Inc. — Statement of Qualifications 11 S e c t i o n H _ Leed Electric Inc. Oct. 8, 2021 LOOMW ELECTRIC City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Firm Name LEED Electric, Inc. Corporate Office Address 13138 Arctic Circle, Santa Fe Springs, CA 90670 Corporate Phone and Fax Numbers Firm Phone # Firm Fax # (562) 270-9500 (562) 863-5723 Federal Tax ID # 95-3337191 Business Type S -Corporation Established 3/1/1979 in California DUNS No.: 09-916-2901 CAGE Code: OXJH1 0048-131380000-1 Exp. Date: 06/30/2022 Business License City of Santa Fe Springs, California License No. 379096 Exp. Date: 07/31/2023 State of California Contractors State License Board Contractor License A - General Engineering Contractor C-10 - Electrical Contractor DIR Contractor Registration DIR Registration No. 1000004633 EXP. Date: 06/30/2022 County of Los Angeles (LSBE) #139996 Exp. Date: 04/30/2022 SBE Certification State of California (Dept. of Gen Services) #36862 Exp. Date: 04/30/2022 NAICS 238210 Seyed A. Jamali Dinan, Chief Executive Officer Principals/Officers Annette Iribarren, Corporate Secretary & Controller Darren Roesch, Operations Manager Rodney Dean, Vice -President & Chief Estimator Years with Company Seth Jamali Dinan: 8 years Rodney Dean: 18 years Telephone and Fax Numbers Phone # Fax # (562) 270-9500 (562) 863-5723 Name, Title, Phone No., and Email of Seth A. Jamali Dinan Contact Person for the Proposal (562) 270-9500 sjamali@leedelectric.com Total # of Employees with the Firm 100 WebVen # 13999601 1ISection I LEED Electric Inc. Oct. 8, 2021 I, MARCH FONG E U, Secretary of State of the State Of California, hereby certify: That the annexed transcript has been compared with the record on file in this office, of which it purports to be a copy, and that same is full, true and correct. IN WITNESS WHEREOF, I execute this certificate and affix the Great Seal of the State of California this MAR 21979 WAA& qMt� (�� Secretary of State SECISTATE FORM CE -107 (REv. t.7s1 f3 !l A .,ee 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24, 25 26 27 28 ENDORSED FILED ARTICLES OF INCORPORATIONibe office of the Secretary of Stato of the State of California OF MAR 31979 MARCH FOND EU, Secretary of Stam LEED ELECTRIC, INC. By BILL HOLDEN Deputy I The name of this corporation is LEED ELECTRIC, INC. II The purpose of this corporation is to engage in any lawful act or activity for which a corporation may be organized under the General Corporation Law of California other than the banking business, the trust company business or the practice of a profession permitted to be incorporated by the California Corporations Code. III The name and address in the State of California of this corporation's initial agent for service of process is: JOANN SEDITA, 1426 North Alta Mesa Way, Brea, California 92621. IV This corporation is authorized to issue only one class of shares of stock; and the total number of shares which this corporation is authorized to issue is 25,000. DATED: February 22, 1979. JZANN SEDITA I hereby declare that I am the person who executed the foregoing Articles of Incorporation, which execution is my act and deed - California Secretary of State op .. Electronic Certified Copy I, ALEX PADILLA, Secretary of State of the State of California, hereby certify that the attached transcript of 2 pages is a full, true and correct copy of the original record in the custody of the California Secretary of State's office. IN WITNESS WHEREOF, I execute this certificate and affix the Great Seal of the State of California on this day of April 03, 2020 QLrz� L ALEX PADILLA Secretary of State Verification Number: P8R2DNK Entity (File) Number: C0884546 To verify the issuance of this Certificate, use the Verification Number above with the Secretary of State Electronic Verification Search available at bizMe. sos. ca.gov wF4!' moa• rhf ay a o California Secretary of State �� .. Electronic Filing Corporation - Statement of Information Entity Name: LEED ELECTRIC, INC. Entity (File) Number: File Date: Entity Type: Jurisdiction: Document ID: Detailed Filing Information 1. Entity Name: 2. Business Addresses: a. Street Address of Principal Office in California: C0884546 04/01/2020 Corporation CALIFORNIA GE57139 LEED ELECTRIC, INC. Secretary of State State of California 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America b. Mailing Address: 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America c. Street Address of Principal Executive Office: 3. Officers: a. Chief Executive Officer: b. Secretary: 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America Seyed Jamali 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America Annette Iribarren 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America Use bizfile.sos.ca.gov for online filings, searches, business records, and resources. I w 1 o California Secretary of State r .. Electronic Filing CSL IFOAA,' Officers (cont'd): c. Chief Financial Officer: 4. Director: Number of Vacancies on the Board of Directors: 5. Agent for Service of Process: 6. Type of Business: Seyed Jamali 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America Seyed Jamali 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America FE Seyed Jamali 13138 Arctic Circle Santa Fe Springs, California 90670 United States of America Electrical Contractor By signing this document, I certify that the information is true and correct and that I am authorized by California law to sign. Electronic Signature: Annette Iribarren Use bizf!le.sos.ca.gov for online filings, searches, business records, and resources. rn M r ti Lo W 0 0 C N E Z V O 1W En■ ��� `CCV ELECTRIC J. DIR Registration/Contractors License City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. —Statement of Qualifications Certificates attached. 11Section 1 Leed Electric Inc. Oct. 8, 2021 License No. 379096 Exp. Date: 07/31/2023 State of California Contractors State License Board Contractor License A - General Engineering Contractor C-10 - Electrical Contractor DIR Contractor Registration DIR Registration No. 1000004633 EXP. Date: 06/30/2022 Certificates attached. 11Section 1 Leed Electric Inc. Oct. 8, 2021 CONTRCTRS STATE LICENASEOBOARD ACTIVE LICENSE 379096 i:01 LEED ELECTRIC INC CORP C10 A 07/31/2023 www.csib.ca.gov Firefox Contractor Information Legal Entity Name LEED ELECTRIC INC Legal Entity Type Corporation Status Active Registration Number 1000004633 Registration effective date 7/1/2021 Registration expiration date 6/30/2022 Mailing Address 13138 ARCTIC CIRCLE SANTA FE SPRINGS 90670 C... Physical Address 13138 ARCTIC CIRCLE SANTA FE SPRINGS 90670 C... Email Address Trade Name/DBA License Number(s) CSLB:379096 CSLB:379096 Legal Entity Information Corporation Number: C0884546 Federal Employment Identification Number: President Name: SEYED JAMALI Vice President Name: RODNEY DEAN Treasurer Name: Secretary Name: ANNETTE IRIBARREN CEO Name: SEYED JAMALI https:Hcadir.secure.force.com/ContractorSearch/PrintRegDetails Agent of Service Name: SEYED JAMALI Agent of Service Mailing Address: 13138 ARCTIC CIRCLE SANTA FE SPRINGS 90670 CA United States of America Workers Compensation 1 of 2 Registration History Effective Date Expiration Date 6/22/2018 6/30/2019 6/13/2017 6/30/2018 6/28/2016 6/30/2017 6/5/2015 6/'30/2016 1/5/2015 6/'30/2015 7/1/2019 6/30/2020 7/1/2020 6/30/2021 7/1/2021 6/'30/2022 10/8/2021, 8:20 AM Firefox https://cadir.secure.force.com/ContractorSearch/PrintRegDetails Do you lease employees No through Professional Employer Organization (PEO)?: Please provide your current workers compensation insurance information below: PEO InformationPEO PEO PEO Name Phone Email Insured by Carrier Policy Holder Name:LEED ELECTRIC INCInsurance Carrier:Zurich American Ins Co Policy Number:WC 3243711-02Inception date:9/30/2020Expiration Date:9/30/2021 2 of 2 10/8/2021, 8:20 AM ■ _�! IMCU ELECTRIC Binding Signatures for LEED Electric, Inc. Rodney Dean Vice -President Seyed A. Jamali Dinan Chief Executive Officer 11 Section K City of Seal Beach RFP On -Call Electrical Maintenance and Repair Services LEED Electric, Inc. — Statement of Qualifications Leed Electric Inc. Oct. 8, 2021 EXHIBIT C TERMS FOR COMPLIANCE WITH CALIFORNIA LABOR LAW REQUIREMENTS 1. This Agreement calls for services that, in whole or in part, constitute "public works" as defined in Division 2, Part 7, Chapter 1 (commencing with Section 1720) of the California Labor Code ("Chapter 1"). Further, Contractor acknowledges that this Agreement is subject to (a) Chapter 1 and (b) the rules and regulations established by the Department of Industrial Relations ("DIR") implementing such statutes. Therefore, as to those Services that are "public works", Contractor shall comply with and be bound by all the terms, rules and regulations described in 1(a) and 1(b) as though set forth in full herein. 2. California law requires the inclusion of specific Labor Code provisions in certain contracts. The inclusion of such specific provisions below, whether or not required by California law, does not alter the meaning or scope of Section 1 above. 3. Contractor shall be registered with the Department of Industrial Relations in accordance with California Labor Code Section 1725.5, and has provided proof of registration to City prior to the Effective Date of this Agreement. Contractor shall not perform work with any subcontractor that is not registered with DIR pursuant to Section 1725.5. Contractor and subcontractors shall maintain their registration with the DIR in effect throughout the duration of this Agreement. If Contractor or any subcontractor ceases to be registered with DIR at any time during the duration of the project, Contractor shall immediately notify City. 4. Pursuant to Labor Code Section 1771.4, Contractor's Services are subject to compliance monitoring and enforcement by DIR. Contractor shall post job site notices, as prescribed by DIR regulations. 5. Pursuant to Labor Code Section 1773.2, copies of the prevailing rate of per diem wages for each craft, classification, or type of worker needed to perform the Agreement are on file at City Hall and will be made available to any interested party on request. Contractor acknowledges receipt of a copy of the DIR determination of such prevailing rate of per diem wages, and Contractor shall post such rates at each job site covered by this Agreement. 6. Contractor shall comply with and be bound by the provisions of Labor Code Sections 1774 and 1775 concerning the payment of prevailing rates of wages to workers and the penalties for failure to pay prevailing wages. Contractor shall, as a penalty to City, forfeit $200.00 for each calendar day, or portion thereof, for each worker paid less than the prevailing rates as determined by the DIR for the work or craft in which the worker is employed for any public work done pursuant to this Agreement by Contractor or by any subcontractor. 7. Contractor shall comply with and be bound by the provisions of Labor Code Section 1776, which requires Contractor and each subcontractor to: keep accurate payroll records and verify such records in writing under penalty of perjury, as specified in Section 1776; certify and make such payroll records available for inspection as provided by Section 1776; and inform City of the location of the records. 8. Contractor shall comply with and be bound by the provisions of Labor Code Sections 1777.5, 1777.6 and 1777.7 and California Code of Regulations, Title 8, Section 200 et seq. concerning the employment of apprentices on public works projects. Contractor shall be responsible for compliance with these aforementioned Sections for all apprenticeable occupations. Prior to commencing work under this Agreement, Contractor shall provide City with a copy of the information submitted to any applicable apprenticeship program. Within 60 days after concluding work pursuant to this Agreement, Contractor and each of its subcontractors shall submit to City a verified statement of the journeyman and apprentice hours performed under this Agreement. 9. Contractor shall not perform work with any Subcontractor that has been debarred or suspended pursuant to California Labor Code Section 1777.1 or any other federal or state law providing for the debarment of contractors from public works. Contractor and subcontractors shall not be debarred or suspended throughout the duration of this Contract pursuant to Labor Code Section 1777.1 or any other federal or state law providing for the debarment of contractors from public works. If Contractor or any subcontractor becomes debarred or suspended during the duration of the project, Contractor shall immediately notify City. 10. Contractor acknowledges that eight hours labor constitutes a legal day's work. Contractor shall comply with and be bound by Labor Code Section 1810. Contractor shall comply with and be bound by the provisions of Labor Code Section 1813 concerning penalties for workers who work excess hours. Contractor shall, as a penalty to City, forfeit $25.00 for each worker employed in the performance of this Agreement by Contractor or by any subcontractor for each calendar day during which such worker is required or permitted to work more than eight hours in any one calendar day and 40 hours in any one calendar week in violation of the provisions of Division 2, Part 7, Chapter 1, Article 3 of the Labor Code. Pursuant to Labor Code Section 1815, work performed by employees of Contractor in excess of eight hours per day, and 40 hours during any one week shall be permitted upon public work upon compensation for all hours worked in excess of eight hours per day at not less than one and one-half times the basic rate of pay. 11. California Labor Code Sections 1860 and 3700 provide that every employer will be required to secure the payment of compensation to its employees. In accordance with the provisions of California Labor Code Section 1861, Contractor hereby certifies as follows: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and 1 will comply with such provisions before commencing the performance of the work of this contract." 12. For every subcontractor who will perform work on the project, Contractor shall be responsible for such subcontractor's compliance with Chapter 1 and Labor Code Sections 1860 and 3700, and Contractor shall include in the written contract between it and each subcontractor a copy of those statutory provisions and a requirement that each subcontractor shall comply with those statutory provisions. Contractor shall be required to take all actions necessary to enforce such contractual provisions and ensure subcontractor's compliance, including without limitation, conducting a periodic review of the certified payroll records of the subcontractor and upon becoming aware of the failure of the subcontractor to pay his or her workers the specified prevailing rate of wages. Contractor shall diligently take corrective action to halt or rectify any failure. 13. To the maximum extent permitted by law, Contractor shall indemnify, hold harmless and defend (at Contractor's expense with counsel reasonably acceptable to City) City, its officials, officers, employees, agents and independent contractors serving in the role of City officials, and volunteers from and against any demand or claim for damages, compensation, fines, penalties or other amounts arising out of or incidental to any acts or omissions listed above by any person or entity (including Contractor, its subcontractors, and each of their officials, officers, employees and agents) in connection with any work undertaken or in connection with the Agreement, including without limitation the payment of all consequential damages, attorneys' fees, and other related costs and expenses. All duties of Contractor under this Section shall survive the termination of the Agreement. ACORO®DATE(MWDOD/YYYY) CERTIFICATE OF LIABILITY INSURANCE INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Aon Risk Insurance Services West, Inc. Los Angeles CA Office Pt FAX (A1C. N..EXt). (866) 283-7122 A C No.): (800) 363-0105 E-MAIL ADDRESS: 707 Wilshire Boulevard Suite 2600 INSURER(S) AFFORDING COVERAGE NAIC # Los Angeles CA 90017-0460 USA INSURED INSURER A: Zurich American Ins Co 16535 Leed Electric, Inc. 13138 Arctic Circle Santa Fe Springs CA 90670 USA INSURER B: RSUI indemnity Company 22314 INSURER C., American Guarantee & Liability Ins Co 26247 INSURERD: Crum & Forster Specialty Insurance Co. 44520 INSURER E: i INSURER F: PREMISES Ea occurrence $300,000 COVERAGES CERTIFICATE NUMBER: 570090250118 REVISION NUM6EH: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. Limits shown are as requested LTR TYPE OF INSURANCE INSD Vivo POLICY NUMBER MM/DD MM/DD LIMITS A X COMMERCIAL GENERAL LIABILITY GLO 230 58 10/01/2021 1 01 022 EACH OCCURRENCE $1,000,000 CLAIMS -MADE X❑OCCUR PREMISES Ea occurrence $300,000 MED EXP (Any one person) $5,000 PERSONAL& ADV INJURY $1,000,000 GEMLAGGREGATELIMITAPPLIESPER: GENERAL AGGREGATE $2,000,000 POLICY ❑X PRO ❑X LOC JECT PRODUCTS - COMP/OP AGG $2,000,000 OTHER: A AUTOMOBILE LIABILITY BAP 3230759 - 03 10/01/202110/01/2022 COMBINED SINGLE LIMIT $1,000,000 Ea accident BODILY INJURY ( Per person) ANY AUTO BODILY INJURY (Per accident) OWNED SCHEDULED AUTOS ONLY AUTOS I PROPERTY D AMAGEHIRED AUTOS NON -OWNED Per accidentONLY AUTOS ONLY Comp./Coll. Ded. $2,500 C UMBRELLA L'OCCUR AUC324371203 10/01/2021 10/01/2022 EACH OCCURRENCE $5,000,000 AGGREGATE $5,000,000 J�E_ CESSLIAR CLAIMS -MADE D RETENTION A WORKERS COMPENSATION AND WC324371103 10/01/202110/01/2022 X PER STATUTE I OTRH- EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE Y/N E.L. EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? (Mandatory In NH) N / A E.L. DISEASE -EA EMPLOYEE $1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE -POLICY LIMIT $1,000,000 D Env Contr Poll PKC112160 10/01/202110/01/2022 Each POLL Condition $2,000,000 Claims Made Deductible $10,000 Aggregate Limit $3,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is requlred) RE: Project info: Seal Beach on -Call Electrical service, LEER Electric Job #T21-040. City of Seal Beach, its elected and appointed officials, officers, employees, agents, designated volunteers and those City agents acting as independent contractors in the role of city officials are included as Additional insured in accordance with the policy provisions of the General Liability and Automobile Liability policies. General Liability policy evidenced herein is Primary and Non-contributory to other insurance available to Additional Insured, but only in accordance with the policy's provisions. A waiver of subrogation is granted in favor of City of seal Beach, its elected and appointed officials, officers, employees, agents, designated, volunteers and those city agents serving as independent contractors in the role of city officials in accordance with the policy CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Seal Beach AUTHORIZED REPRESENTATIVE 211 -8th Street Seal Beach Az 90740 USA 0 U C3 m d d O S cc LO N 0 0 r� Lo O Z m m t) .L. d U ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016/03) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: 570000069943 LOC #: ADDITIONAL REMARKS SCHEDULE Page _ of _ AGENCY Aon Risk Insurance Services West, Inc. NAMEDINSURED Leed Electric, Inc. POLICY NUMBER See Certificate Number: 570090250118 CARRIER See Certificate Number: 570090250118 NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance INSURER(S) AFFORDING COVERAGE NAIC # INSURER INSURER POLICY INSURER INSURER ADDITIONAL POLICIES If a policy below does not include limit information, refer to the corresponding policy on the ACORD certificate form for policy limits. ACORD 101 (2008/01) G) ZUUt3 AWHU GUnt'UHAUUrl. w1 ngnrs rUb—CU. The ACORD name and logo are registered marks of ACORD POLICY POLICY INSR ADDL SUBR POLICYNUMBER EFFECTIVE EXPIRATION LIMITS LTR TYPE OF INSURANCE INSD W VD DATE DATE (MMIDDIYYYY) (MM/DD/YYYY) EXCESS LIABILITY B NHA252429 10/01/2021 10/01/2022 Aggregate $5,000,000 OTHER ACORD 101 (2008/01) G) ZUUt3 AWHU GUnt'UHAUUrl. w1 ngnrs rUb—CU. The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: 570000069943 LOC #: A� ADDITIONAL REMARKS SCHEDULE Page _ of _ AGENCY Aon Risk Insurance Services West, Inc. NAMED INSURED Leed Electric, Inc. POLICY NUMBER see certificate Number: 570090250118 CARRIER see certificate Number: 570090250118 NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance Additional Description of Operations / Locations / Vehicles: provisions of the General Liability, Automobile Liability and workers' compensation policies. ACORD 101 (2006/01) V 2UUt5 AWKIJ L;UKFUHA1 run. An ❑gnrs reserves. The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: 570000069943 LOC #: Ak---- ADDITIONAL REMARKS SCHEDULE Page _ of _ AGENCY Aon Risk Insurance Services West, Inc. NAMED INSURED Leed Electric, Inc. POLICY NUMBER see certificate Number: 570090250118 CARRIER see certificate Number: 570090250118 NAIC CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 .FORM TITLE: Certificate of Liability Insurance Excess Liability Policy # MXL0431782 Policy term : 10/1/2021 to 10/1/2022 Underwriter company name : Mt. Hawley Insurance company Each Occurrence $ 5,000,000 Aggregate $5,000,000 Policy # PUB786667 Policy term : 10/1/2021 to 10/1/2022 Underwriter company name: Tokio Marine Specialty Insurance Each occurrence 10,000,000 General Aggregate 10,000,000 ACORD 101 (2008/01) 0 ZWO AL Unu eUnrur1A11Un. Au ngms MbUFV a. The ACORD name and Logo are registered marks of ACORD a Additional Insured —Automatic — Owners, Lessees Or ZURICH® Contractors Policy No. I Eff. Date of Pol. I Exp. Date of Pol. I Eff. Date of End. I Producer No. I Add'I. Prem Return Prem. G LO -3230758-03 10/01 /2021 110/01/2022 110/01/2021 5272000 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Named Insured: Address (including ZIP Code): Leed Electric, Inc. 13138 Arctic Circle Santa Fe Springs, CA 90670 This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part A. Section II — Who Is An Insured is amended to include as an additional insured any person or organization whom you are required to add as an additional insured on this policy under a written contract or written agreement. Such person or organization is an additional insured only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury' caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf, in the performance of your ongoing operations or "your work" as included in the "products -completed operations hazard", which is the subject of the written contract or written agreement. However, the insurance afforded to such additional insured: 1. Only applies to the extent permitted by law; and 2. Will not be broader than that which you are required by the written contract or written agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following additional exclusion applies: This insurance does not apply to: "Bodily injury", "property damage" or "personal and advertising injury' arising out of the rendering of, or failure to render, any professional architectural, engineering or surveying services including: a. The preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or b. Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional architectural, engineering or surveying services. U -GL -1175-F CW (04113) Page 1 of 2 Includes copyrighted material of Insurance Services Office, Inc., with its permission. C. The following is added to Paragraph 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit of Section IV — Commercial General Liability Conditions: The additional insured must see to it that: 1. We are notified as soon as practicable of an "occurrence" or offense that may result in a claim; 2. We receive written notice of a claim or "suit" as soon as practicable; and 3. A request for defense and indemnity of the claim or "suit" will promptly be brought against any policy issued by another insurer under which the additional insured may be an insured in any capacity. This provision does not apply to insurance on which the additional insured is a Named Insured if the written contract or written agreement requires that this coverage be primary and non-contributory. D. For the purposes of the coverage provided by this endorsement: 1. The following is added to the Other Insurance Condition of Section IV — Commercial General Liability Conditions: Primary and Noncontributory insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured provided that: a. The additional insured is a Named Insured under such other insurance; and b. You are required by written contract or written agreement that this insurance be primary and not seek contribution from any other insurance available to the additional insured. 2. The following paragraph is added to Paragraph 4.b. of the Other Insurance Condition of Section IV — Commercial General Liability Conditions: This insurance is excess over: Any of the other insurance, whether primary, excess, contingent or on any other basis, available to an additional insured, in which the additional insured on our policy is also covered as an additional insured on another policy providing coverage for the same "occurrence", offense, claim or "suit". This provision does not apply to any policy in which the additional insured is a Named Insured on such other policy and where our policy is required by a written contract or written agreement to provide coverage to the additional insured on a primary and non- contributory basis. E. This endorsement does not apply to an additional insured which has been added to this policy by an endorsement showing the additional insured in a Schedule of additional insureds, and which endorsement applies specifically to that identified additional insured. F. With respect to the insurance afforded to the additional insureds under this endorsement, the following is added to Section 111— Limits Of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the written contract or written agreement referenced in Paragraph A. of this endorsement; or 2. Available under the applicable Limits of Insurance shown in the Declarations, whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. All other terms and conditions of this policy remain unchanged. U -GL -1175-F CW (04113) Page 2 of 2 Includes copyrighted material of Insurance Services Office, Inc., with its permission. POLICY NUMBER: GLO-3230758-03 COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: Any Person or Organization that requires You to waive your Rights of Recovery, in a written contract or agree- ment with the Named Insured that is executed prior to the accident or loss. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV — Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products - completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 05 09 © Insurance Services Office, Inc., 2008 Page 1 of 1 Wolters Kluwer Financial Services I Uniform FormsTM Coverage Extension Endorsement ZURICHO Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff. Date of End. Producer No. Add'I. Prem Return Prem. BAP -3230759-03 10/01/2021 10/01/2022 10/01/2021 5272000 -------------- ------------ THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Business Auto Coverage Form Motor Carrier Coverage Form A. Amended Who Is An Insured 1. The following is added to the Who Is An Insured Provision in Section II — Covered Autos Liability Coverage: The following are also "insureds": a. Any "employee" of yours is an "insured" while using a covered "auto" you don't own, hire or borrow for acts performed within the scope of employment by you. Any "employee" of yours is also an "insured" while operating an "auto" hired or rented under a contract or agreement in an "employee's" name, with your permission, while performing duties related to the conduct of your business. b. Anyone volunteering services to you is an "insured" while using a covered "auto" you don't own, hire or borrow to transport your clients or other persons in activities necessary to your business. c. Anyone else who furnishes an "auto" referenced in Paragraphs A.1.a. and A.1.b. in this endorsement. d. Where and to the extent permitted by law, any person(s) or organization(s) where required by written contract or written agreement with you executed prior to any "accident", including those person(s) or organization(s) directing your work pursuant to such written contract or written agreement with you, provided the "accident" arises out of operations governed by such contract or agreement and only up to the limits required in the written contract or written agreement, or the Limits of Insurance shown in the Declarations, whichever is less. 2. The following is added to the Other Insurance Condition in the Business Auto Coverage Form and the Other Insurance — Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form: Coverage for any person(s) or organization(s), where required by written contract or written agreement with you executed prior to any "accident", will apply on a primary and non-contributory basis and any insurance maintained by the additional "insured" will apply on an excess basis. However, in no event will this coverage extend beyond the terms and conditions of the Coverage Form. B. Amendment— Supplementary Payments Paragraphs a.(2) and a.(4) of the Coverage Extensions Provision in Section II — Covered Autos Liability Coverage are replaced by the following: (2) Up to $5,000 for the cost of bail bonds (including bonds for related traffic law violations) required because of an "accident" we cover. We do not have to furnish these bonds. (4) All reasonable expenses incurred by the "insured" at our request, including actual loss of earnings up to $500 a day because of time off from work. U -CA -424-F CW (04114) Page 1 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. C. Fellow Employee Coverage The Fellow Employee Exclusion contained in Section 11— Covered Autos Liability Coverage does not apply. D. Driver Safety Program Liability and Physical Damage Coverage 1. The following is added to the Racing Exclusion in Section II — Covered Autos Liability Coverage: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. 2. The following is added to Paragraph 2. in the Exclusions of Section III — Physical Damage Coverage of the Business Auto Coverage Form and Paragraph 2.b. in the Exclusions of Section IV — Physical Damage Coverage of the Motor Carrier Coverage Form: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. E. Lease or Loan Gap Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Lease Or Loan Gap Coverage In the event of a total 'loss" to a covered "auto", we will pay any unpaid amount due on the lease or loan for a covered "auto", less: a. Any amount paid under the Physical Damage Coverage Section of the Coverage Form; and b. Any: (1) Overdue lease or loan payments at the time of the 'loss'; (2) Financial penalties imposed under a lease for excessive use, abnormal wear and tear or high mileage; (3) Security deposits not returned by the lessor; (4) Costs for extended warranties, credit life insurance, health, accident or disability insurance purchased with the loan or lease; and (5) Carry-over balances from previous leases or loans. F. Towing and Labor Paragraph A.2. of the Physical Damage Coverage Section is replaced by the following: We will pay up to $75 for towing and labor costs incurred each time a covered "auto" of the private passenger type is disabled. However, the labor must be performed at the place of disablement. G. Extended Glass Coverage The following is added to Paragraph A.3.a. of the Physical Damage Coverage Section: If glass must be replaced, the deductible shown in the Declarations will apply. However, if glass can be repaired and is actually repaired rather than replaced, the deductible will be waived. You have the option of having the glass repaired rather than replaced. H. Hired Auto Physical Damage — Increased Loss of Use Expenses The Coverage Extension for Loss Of Use Expenses in the Physical Damage Coverage Section is replaced by the following: Loss Of Use Expenses For Hired Auto Physical Damage, we will pay expenses for which an "insured" becomes legally responsible to pay for loss of use of a vehicle rented or hired without a driver under a written rental contract or written rental agreement. We will pay for loss of use expenses if caused by: U -CA -424-F CW (04114) Page 2 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. (1) Other than collision only if the Declarations indicate that Comprehensive Coverage is provided for any covered "auto'; (2) Specified Causes Of Loss only if the Declarations indicate that Specified Causes Of Loss Coverage is provided for any covered "auto'; or (3) Collision only if the Declarations indicate that Collision Coverage is provided for any covered "auto". However, the most we will pay for any expenses for loss of use is $100 per day, to a maximum of $3000. I. Personal Effects Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Personal Effects Coverage a. We will pay up to $750 for "loss" to personal effects which are: (1) Personal property owned by an "insured"; and (2) In or on a covered "auto". b. Subject to Paragraph a. above, the amount to be paid for "loss" to personal effects will be based on the lesser of: (1) The reasonable cost to replace; or (2) The actual cash value. c. The coverage provided in Paragraphs a. and b. above, only applies in the event of a total theft of a covered "auto". No deductible applies to this coverage. However, we will not pay for 'loss" to personal effects of any of the following: (1) Accounts, bills, currency, deeds, evidence of debt, money, notes, securities, or commercial paper or other documents of value. (2) Bullion, gold, silver, platinum, or other precious alloys or metals; furs or fur garments; jewelry, watches, precious or semi-precious stones. (3) Paintings, statuary and other works of art. (4) Contraband or property in the course of illegal transportation or trade. (5) Tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. Any coverage provided by this Provision is excess over any other insurance coverage available for the same "loss". J. Tapes, Records and Discs Coverage 1. The Exclusion in Paragraph 13.4.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph 6.2.c. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply. 2. The following is added to Paragraph 1.a. Comprehensive Coverage under the Coverage Provision of the Physical Damage Coverage Section: We will pay for 'loss" to tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. We will pay only if the tapes, records, discs or other similar audio, visual or data electronic devices: (a) Are the property of an "insured'; and (b) Are in a covered "auto" at the time of "loss". The most we will pay for such 'loss" to tapes, records, discs or other similar devices is $500. The Physical Damage Coverage Deductible Provision does not apply to such 'loss". U -CA -424-F CW (04/14) Page 3 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. K. Airbag Coverage The Exclusion in Paragraph 13.3.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph BA.a. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply to the accidental discharge of an airbag. L. Two or More Deductibles The following is added to the Deductible Provision of the Physical Damage Coverage Section: If an accident is covered both by this policy or Coverage Form and by another policy or Coverage Form issued to you by us, the following applies for each covered "auto" on a per vehicle basis: 1. If the deductible on this policy or Coverage Form is the smaller (or smallest) deductible, it will be waived; or 2. If the deductible on this policy or Coverage Form is not the smaller (or smallest) deductible, it will be reduced by the amount of the smaller (or smallest) deductible. M. Physical Damage — Comprehensive Coverage — Deductible The following is added to the Deductible Provision of the Physical Damage Coverage Section: Regardless of the number of covered "autos" damaged or stolen, the maximum deductible that will be applied to Comprehensive Coverage for all "loss" from any one cause is $5,000 or the deductible shown in the Declarations, whichever is greater. N. Temporary Substitute Autos — Physical Damage 1. The following is added to Section I — Covered Autos: Temporary Substitute Autos — Physical Damage If Physical Damage Coverage is provided by this Coverage Form on your owned covered "autos", the following types of vehicles are also covered "autos" for Physical Damage Coverage: Any "auto" you do not own when used with the permission of its owner as a temporary substitute for a covered "auto" you do own but is out of service because of its: 1. Breakdown; 2. Repair; 3. Servicing; 4. "Loss'; or 5. Destruction. 2. The following is added to the Paragraph A. Coverage Provision of the Physical Damage Coverage Section: Temporary Substitute Autos — Physical Damage We will pay the owner for "loss" to the temporary substitute "auto" unless the "loss" results from fraudulent acts or omissions on your part. If we make any payment to the owner, we will obtain the owner's rights against any other party. The deductible for the temporary substitute "auto" will be the same as the deductible for the covered "auto" it replaces. O. Amended Duties In The Event Of Accident, Claim, Suit Or Loss Paragraph a. of the Duties In The Event Of Accident, Claim, Suit Or Loss Condition is replaced by the following: a. In the event of "accident", claim, "suit" or "loss", you must give us or our authorized representative prompt notice of the "accident", claim, "suit" or "loss". However, these duties only apply when the "accident", claim, "suit" or "loss" is known to you (if you are an individual), a partner (if you are a partnership), a member (if you are a limited liability company) or an executive officer or insurance manager (if you are a corporation). The failure of any U -CA -424-F CW (04/14) Page 4 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. agent, servant or employee of the "insured" to notify us of any "accident", claim, "suit" or "loss" shall not invalidate the insurance afforded by this policy. Include, as soon as practicable: (1) How, when and where the "accident" or "loss" occurred and if a claim is made or "suit" is brought, written notice of the claim or "suit" including, but not limited to, the date and details of such claim or "suit'; (2) The "insured's" name and address; and (3) To the extent possible, the names and addresses of any injured persons and witnesses. If you report an "accident", claim, "suit" or "loss" to another insurer when you should have reported to us, your failure to report to us will not be seen as a violation of these amended duties provided you give us notice as soon as practicable after the fact of the delay becomes known to you. P. Waiver of Transfer Of Rights Of Recovery Against Others To Us The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: This Condition does not apply to the extent required of you by a written contract, executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises out of operations contemplated by such contract. This waiver only applies to the person or organization designated in the contract. Q. Employee Hired Autos — Physical Damage Paragraph b. of the Other Insurance Condition in the Business Auto Coverage Form and Paragraph f. of the Other Insurance — Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form are replaced by the following: For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own: (1) Any covered "auto" you lease, hire, rent or borrow; and (2) Any covered "auto" hired or rented under a written contract or written agreement entered into by an "employee" or elected or appointed official with your permission while being operated within the course and scope of that "employee's" employment by you or that elected or appointed official's duties as respect their obligations to you. However, any "auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto". R. Unintentional Failure to Disclose Hazards The following is added to the Concealment, Misrepresentation Or Fraud Condition: However, we will not deny coverage under this Coverage Form if you unintentionally: (1) Fail to disclose any hazards existing at the inception date of this Coverage Form; or (2) Make an error, omission, improper description of "autos" or other misstatement of information. You must notify us as soon as possible after the discovery of any hazards or any other information that was not provided to us prior to the acceptance of this policy. S. Hired Auto —World Wide Coverage Paragraph 7a.(5) of the Policy Period, Coverage Territory Condition is replaced by the following: (5) Anywhere in the world if a covered "auto" is leased, hired, rented or borrowed for a period of 60 days or less, T. Bodily Injury Redefined The definition of "bodily injury" in the Definitions Section is replaced by the following: "Bodily injury" means bodily injury, sickness or disease, sustained by a person including death or mental anguish, resulting from any of these at any time. Mental anguish means any type of mental or emotional illness or disease. U -CA -424-F CW (04114) Page 5 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. U. Expected Or Intended Injury The Expected Or Intended Injury Exclusion in Paragraph B. Exclusions under Section 11— Covered Auto Liability Coverage is replaced by the following: Expected Or Intended Injury "Bodily injury" or "property damage" expected or intended from the standpoint of the "insured". This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. V. Physical Damage — Additional Temporary Transportation Expense Coverage Paragraph AA.a. of Section III — Physical Damage Coverage is replaced by the following: 4. Coverage Extensions a. Transportation Expenses We will pay up to $50 per day to a maximum of $1,000 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. We will pay for temporary transportation expenses incurred during the period beginning 48 hours after the theft and ending, regardless of the policy's expiration, when the covered "auto" is returned to use or we pay for its "loss". W. Replacement of a Private Passenger Auto with a Hybrid or Alternative Fuel Source Auto The following is added to Paragraph A. Coverage of the Physical Damage Coverage Section: In the event of a total "loss" to a covered "auto" of the private passenger type that is replaced with a hybrid "auto" or "auto" powered by an alternative fuel source of the private passenger type, we will pay an additional 10% of the cost of the replacement "auto", excluding tax, title, license, other fees and any aftermarket vehicle upgrades, up to a maximum of $2500. The covered "auto" must be replaced by a hybrid "auto" or an "auto" powered by an alternative fuel source within 60 calendar days of the payment of the "loss" and evidenced by a bill of sale or new vehicle lease agreement. To qualify as a hybrid "auto", the "auto" must be powered by a conventional gasoline engine and another source of propulsion power. The other source of propulsion power must be electric, hydrogen, propane, solar or natural gas, either compressed or liquefied. To qualify as an "auto" powered by an alternative fuel source, the "auto" must be powered by a source of propulsion power other than a conventional gasoline engine. An "auto" solely propelled by biofuel, gasoline or diesel fuel or any blend thereof is not an "auto" powered by an alternative fuel source. X. Return of Stolen Automobile The following is added to the Coverage Extension Provision of the Physical Damage Coverage Section: If a covered "auto" is stolen and recovered, we will pay the cost of transport to return the "auto" to you. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. All other terms, conditions, provisions and exclusions of this policy remain the same. U -CA -424-F CW (04/14) Page 6 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY INSURANCE POLICY WC 04 03 06 (Ed. 4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT - CALIFORNIA This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following "attaching clause" need be completed only when this endorsement is issued subsequent to preparation of the policy.) This endorsement, effective on 10/01/2021 at 12:01 A.M. standard time, forms a part of (DATE) Policy No. WC -3243711-03 Endorsement No. of the Zurich American Insurance Company issued to Leed Electric, Inc. Premium (if any) $ Authorized Representative We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be % of the California workers' compensation pre- mium otherwise due on such remuneration. Schedule Person or Organization Job Description ALL PERSONS AND/OR ORGANIZATIONS THAT ARE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT WITH THE INSURED, EXECUTED PRIOR TO THE ACCIDENT OR LOSS, THAT WAIVER OF SUBROGATION BE PROVIDED UNDER THIS POLICY FOR WORK PERFORMED BY YOU FOR THAT PERSON AND/OR ORGANIZATION. WC 252 (4-84) Page 1 of 1 WC 04 03 06 (Ed. 4-84)