HomeMy WebLinkAboutAGMT - Doty Bros. (Water & Sewer Line Repairs) •
p-zeQd ca,ce..f \- 1,-)rl r
io:. /o I
-. _afar,.._ �* -✓�L� ( �n2 /2 1�cww
AGREEMENT FOR CONTRACT SERVICES
THIS AGREEMEN O CONTRACT SERVICES (the "Agreement ") is made and entered
into as day o��L , 2001 by and between the CITY OF SEAL BEACH, a municipal
corporation ( "City") and Doty Bros. Equipment Co., a California corporation ( "Contractor ").
RECITALS
WHEREAS, City desires to employ the services of Contractor to provide emergency
services, maintenance and unit price contract services for City; and
WHEREAS, Contractor represents that it has the expertise and experience to provide
such services.
NOW THEREFORE, and for good consideration, the City and Contractor agree as
follows:
1. On Call Services. Contractor shall provide the services described below on an as
needed basis on City-owned water lines and sewers at various locations citywide.
Contractor shall not proceed with any work unless the Director of Public Works or his
authorized designee provides prior written work authorization/order to Contractor. .
2. Description of Services to be Provided. Contractor shall furnish all labor, materials,
tools and equipment for the repair of water lines and sewer lines in the event of a
failure of the City's water distribution/pumping system or sewer collection/pumping
system.
2.1 Standard Specifications Except as otherwise provided herein, all Work shall be done,
and the contract shall be performed, in accordance with the provisions of the most
current edition of "STANDARD SPECIFICATIONS FOR PUBLIC WORKS
CONSTRUCTION" (commonly known as "the GREEN BOOK ") including
Supplements, prepared and promulgated by the Southern California Chapter of the
American Public Works Association and the Associated General Contractors of
California, which specifications are hereinafter referred to as the "Standard
Specifications."
3. Term. Subject to the termination provisions set forth hereinbelow, the term of this
Agreement shall be one (1) year from the date of execution. The parties may extend
the term by written mutual agreement on a year -to -year basis not to exceed an
additional five (5) years.
4. Party Representatives.
The City designates the following person to act on the City's behalf:.
IP
Douglas A. Dancs, P.E., Director of Public Works
The Contractor designates the following person to act on Contractor's behalf:
Scott E. Doty, Asst. Division Manager
5. Attachments. This Agreement incorporates by reference the following Attachments to
this Agreement:
Attachment 1: SCHEDULE OF COMPENSATION
6. Integration. This Agreement represents the entire understanding of City and
Contractor as to those matters contained herein. No prior oral or written
understanding shall be of any force or effect with regard to those matters covered by
this Agreement. This Agreement supersedes and cancels any and all previous •
negotiations, arrangements, agreements, and understandings, if any, between the ,
parties, and none shall be used to interpret this Agreement. This Agreement may only
be amended by the mutual consent of the parties by an instrument in writing.
7. Standard of Performance. Contractor agrees that all services shall be performed in a
competent, professional, and satisfactory manner in accordance with the standards
prevalent in the industry, and that all goods, materials, equipment or personal property
included within the services herein shall be of good quality, fit for the purpose
intended.
8. Performance to Satisfaction of City. Contractor agrees to perform all work to the
satisfaction of City within the time specified. If Contractor's work is not satisfactory
in the opinion of City's designated representative, City has the right to take
appropriate action, including but not limited to any or all of the following: (i) meeting
with Contractor to review the quality of the work and resolve matters of concern; (ii)
requiring Contractor to repeat or correct the work at no additional fee until it is
satisfactory; (iii) suspending the delivery of new or additional work to Contractor for
an indefinite time; (iv) withholding payment; and (v) terminating this Agreement as
hereinafter set forth. City's options set forth herein are non - exclusive, and are in
addition to any remedy available at law to City.
9. Prohibition Against Subcontracting or Assignment. Contractor shall not contract
with any other entity to perform in whole or in part the services required hereunder
without the express written approval of City. In addition, neither the Agreement nor
any interest herein . may be transferred, assigned, conveyed, hypothecated, or
encumbered voluntarily or by operation of law, whether for the benefit of creditors or
otherwise, without the prior written approval of City. In the event of any unapproved
transfer, including in any bankruptcy proceeding, City may void the Agreement at
City's option in its sole and absolute discretion. No approved transfer shall release
any surety of Contractor of any liability hereunder without the express consent of City.
10. Compensation. Contractor shall be compensated per attached Schedule of
Compensation supplied in Attachment 1.
2
For the second and subsequent contract years the Contractor may petition the City for
an increase in the hourly rates set forth in Attachment 1 on the basis of: (a) unusual
changes in his cost of doing business, due to revised laws or regulations, over which
the Contractor has no control; or (b) a yearly increase in the C.P.I. in excess of three
percent over the preceding year.
In order to justify an increase, the Contractor shall submit financial and accounting
data to the City which clearly substantiates the requested increase. After consideration
of such financial and accounting data as submitted by the Contractor and any other
relevant information, the City Council shall disapprove, approve, or approve with
modification the requested increase. The decision of the City Council shall be fmal
and conclusive. The Contractor agrees to abide by the City Council's decision.
11. Insurance. Contractor shall have insurance as follows:
11.1 General Liability (including premises and operations, contractual liability,
personal injury, independent contractors liability): One Million Dollars
(S1,000,000.00) Single Limit, per occurrence. If commercial general liability
insurance or other form with a general aggregate limit is used, either the general
aggregate shall apply separately to this project, or the general aggregate limit
shall be three times the occurrence limit.
11.2 Automobile Liability (including owned, non - owned, and hired autos): One
Million Dollars ($1,000,000.00), Single limit, per occurrence for bodily injury
and property damage.
11.3 Employer's Liability One Million Dollars ($1,000,000.00) per occurrence for
injuries incurred in providing services under this Agreement (if Contractor is
required to have per the laws of California).
11.4 Workers Compensation Contractor shall, to the extent required by state law,
provide Employee's Insurance Workers' Compensation Insurance for the
protection of Contractor's employees. Contractor shall file a certificate of
insurance which evidences that Contractor is in compliance with said Worker's
Compensation Insurance requirement. Contractor shall require all subcontractors
similarly to provide such Workers' Compensation Insurance and certificates of
insurance for their respective employees.
11.5 General Requirements. All of Contractor's and its sub - contractor's policies of
insurance shall:
A. Name City, its officers, officials, employees, agents,
representatives and volunteers (collectively hereinafter "City and City
Personnel ") as additional insureds and contain no special limitations on the
scope of protection afforded to City and City Personnel;
B. Be primary insurance and shall provide that any insurance or
self- insurance maintained by City or City Personnel shall be in excess of
Contractor's insurance and shall not contribute with it;
3
C. Be "occurrence" rather than "claims made" insurance;
D. Apply separately to each insured against whom claim is made
or suit is brought, except with respect to the limits of the insurer's liability;
E. Be endorsed to state that the insurer shall waive all rights of
subrogation against City and City Personnel; and
F. Be written by good and solvent insurer(s) admitted to do
business in the State of California and acceptable to City.
11.6 Deductibles. Any deductibles or self - insured retentions must be declared
to and approved by City prior to the execution of this Agreement by City.
11.7 Notice of Policy Changes. Each such insurance policy shall be endorsed
to state that coverage shall not be suspended, voided, cancelled, reduced in coverage
or in limits, non - renewed, or materially changed for any reason, without thirty (30)
days prior written notice thereof given by the insurer to City by U.S. mail, certified, or
by personal delivery. In addition to such notice provided to City by the insurer,
Contractor shall also provide City with thirty (30) days prior written notice, by
certified mail return receipt requested, of the suspension, voiding, cancellation,
reduction in coverage or in limits, non - renewal, or material change for any reason, of
any such insurance policy or policies.
11.8 Evidence of Coverage. Contractor shall furnish City with certificates of
insurance demonstrating the coverage required by this Agreement which shall be
received and approved by City not less than five (5) working days before work
commences. The duplicate originals and original endorsements for each insurance
policy shall be signed by a person authorized by that insurer to bind coverage on its
behalf. The procuring of such insurance or the delivery of duplicate originals and
endorsements evidencing the same shall not be construed as a limitation on
Contractor's obligation to indemnify City and City Personnel.
12. Indemnification. Contractor shall indemnify, defend, and hold City and City
Personnel harmless from and against any and all actions, claims, demands, judgments,
attorney's fees, costs, damage to persons or property, penalties, obligations, expenses
or liabilities that may be asserted or claimed by any person or entity arising out of the
acts, errors, or omissions of Contractor, its employees, agents, representatives or
subcontractors in the performance of any tasks or services for or on behalf of City,
whether or not there is concurrent active or passive negligence on the part of City
and/or City Personnel; provided, however, that the Contractor shall not be required to
indemnify, defend or hold harmless City or City Personnel against claims arising from
the sole active negligence or willful misconduct of City or City Personnel. In
connection therewith:
12.1 Contractor shall defend, with Counsel acceptable to City, any action or
actions filed in connection with any such claimed damage, injury, penalty, obligation
or liability, and shall pay all costs and expenses, including attorney's fees, incurred
therewith.
4
• •
12.2 In the event City and/or any City Personnel is made a party to any action
or proceeding filed or prosecuted for any such claimed damage, injury, penalty,
obligation or liability, Contractor shall defend City and pay to City any and all costs
and expenses incurred by City in such action or proceeding, together with actual
attorney's fees and expert witness fees.
13. Compliance with Laws. Contractor shall keep fully informed of all State and Federal
laws and County and Municipal ordinances and regulations which in any manner
affect those employed by it or in any way affect the performance of services pursuant
to this Agreement. Contractor shall at all times observe and comply with all such
laws, ordinances, and regulations and shall be responsible for the compliance of all
work and services performed by or on behalf of Contractor. Each and every provision
required by law to be inserted into this Agreement shall be deemed to be inserted, and
this Agreement shall be read and enforced as though they were included.
13.1 This contract is subject to the provisions of Article 1.5 (commencing at
Section 20104) of Division 2, Part 3 of the California Public Contract Code regarding
the resolution of public works claims of less than $375,000. Article 1.5 mandates
certain procedures for the filing of claims and supporting documentation by the
contractor, for the response to such claims by the contracting public agency, for a
mandatory meet and confer conference upon the request of the contractor, for
mandatory nonbinding mediation in the event litigation is commenced, and for
mandatory judicial arbitration upon the failure to resolve the dispute through
mediation. This contract hereby incorporates the provisions of Article 1.5 as though
fully set forth herein.
13.2 This contract is further subject to the provisions of Article 1.7
(commencing at Section 20104.50) of Division 2, Part 3 of the California Public
Contract Code regarding prompt payment of contractors by local governments.
Article 1.7 mandates certain procedures for the payment of undisputed and properly
submitted payment requests within 30 days after receipt, for the review of payment
requests, for notice to the contractor of improper payment requests, and provides for
the payment of interest on progress payment requests which are not timely made in
accordance with this Article. This contract hereby incorporates the provisions. of
Article 1.7 as though fully set forth herein.
14. Independent Contractor. Contractor shall perform all services required herein as an
independent contractor of City and shall remain at all times as to City a wholly
independent contractor. City shall not in any way or for any purpose become or be
deemed to be a partner or employer of Contractor in its business or otherwise, or a
joint venturer, or a member of any joint enterprise with Contractor. Contractor shall
not at any time or in any manner represent that it or any of its agents or employees are
agents or employees of City. Neither Contractor nor any of Contractor's employees
shall, at any time, or in any way, be entitled to any sick leave, vacation, retirement, or
other fringe benefits from City; and neither Contractor nor any of its employees shall
be paid by City any wage or overtime benefit. City is under no obligation to withhold
State and Federal tax deductions from Contractor's compensation. Neither Contractor
nor any of Contractor's employees shall be included in the competitive service, have
any property right to any position, or any of the rights a City employee might
otherwise have in the event of termination of employment.
5
15. Covenant Against Discrimination. Contractor covenants for itself, its heirs,
executors, assigns, and all persons claiming under or through it, that there shall be no
discrimination against any person on account of race, color, creed, relation, sex,
marital status, national origin, or ancestry, in the performance of this Agreement.
Contractor further covenants and agrees to comply with the terms of the Americans
with Disabilities Act of 1990 (42 U.S.C. §12101 et seq.) as the same may be amended
from time to time.
16. Termination By City. City reserves the right to terminate this Agreement at any
time, with or without cause, upon written notice to Contractor. Upon receipt of any
notice of termination from City, Contractor shall immediately cease all services
hereunder except such as may be specifically approved in writing by City. Contractor
shall be entitled to compensation for all services rendered prior to receipt of City's
notice of termination and for any services authorized in writing by City thereafter.
17. Waiver. No delay or omission in the exercise of any right or remedy by a non-
defaulting party on any default shall impair such right or remedy or be construed as a
waiver. A party's consent to or approval of any act by the other party require the
party's consent or approval shall not be deemed to waive or render unnecessary the
other party's consent to or approval of any subsequent act. Any waiver by either party
of any default must be in writing and shall not be a waiver of any other default
concerning the same or any other provision of this Agreement.
18. Legal Actions. The Municipal and Superior Courts of the State of California in the
County of Orange shall have the exclusive jurisdiction of any litigation between the
parties arising out of this Agreement. This Agreement shall be governed by, and
construed under, the laws of the State of California. The rights and remedies of the
parties are cumulative and the exercise by either party of one or more of such rights or
remedies shall not preclude the exercise by it, at the same or different times, of any
other rights or remedies for the same default or any other default by the other party.
19. Attorneys' Fees. if either party to this Agreement is required to initiate or defend, or
is made a party to, any action or proceeding in any way connected with this
Agreement, the party prevailing in the final judgment in such action or proceeding, in
addition to any other relief which may be granted, shall be entitled to litigation costs,
including actual attorney's fees- and expert witness fees.
20. Force Majeure. The time period specified in this Agreement for performance of
work may be extended by City because of any delays due to unforeseeable causes
beyond the control and without the fault or negligence of Contractor, including, but
not restricted to, acts of God or of the public enemy, unusually severe weather, fires,
earthquakes, floods, epidemics, quarantine restrictions, riots, strikes, freight
embargoes, wars, litigation, and/or acts of any governmental agency, including City,
provided that Contractor shall within ten (10) days of the commencement of such
delay notify City in writing of the causes and length of the delay. If Contractor gives
notice of such delay, City shall ascertain the facts and the extent of delay, and extend
the time for performing the services for the period of the enforced delay, when and if
in the judgments of City, such delay is justified. City's determination shall be made in
writing, and shall be final and conclusive upon the parties to this Agreement. In no
event shall Contractor be entitled to recover damages against City for any delay in the
6
performance of this Agreement, however caused. Contractor's sole remedy shall be
•
extension of this Agreement. -
21. Notices. Unless otherwise provided herein, all notices required to be delivered under
this Agreement or under applicable law shall be personally delivered, or delivered by
United States mail, prepaid, certified, return receipt requested, or by reputable
document delivery service that provides a receipt showing date and time of delivery.
Notices personally delivered or delivered by a document delivery service shall be
effective upon receipt. Notices delivered by,mail shall be effective at 5:00 p.m. on the
second calendar day following dispatch. Notices shall be delivered to the following
addresses:
To City:
Doug Dancs, P.E., Director of Public Works /City Engineer
City of Seal Beach
211 Eighth Street
Seal Beach, 90740
To Contractor:
Scott E. Doty, Asst. Division Manager
Doty Bros. Equipment Co.
11232 Firestone Blvd.
Norwalk, CA 90650
22. Time of Essence. Time is of the essence in the performance of this Agreement.
•
23. Interpretation: Severabilitv. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of this Agreement or any other rule of
construction which might otherwise apply. The Section headings are for purposes of
convenience only, and shall not be construed to limit or extend the meaning of this
Agreement. Each provision of this Agreement shall be severable from the whole. If
any provision of this Agreement shall be found contrary to law, the remainder of this
Agreement shall continue in full force.
•
24. Corporate Authority. The person(s) executing this Agreement on behalf of the
parties hereto warrant that (i) such party is duly organized and existing, (ii) they are
duly authorized to execute and deliver this Agreement on behalf of said party, (iii) by
so executing this Agreement, such party is formally bound to the provisions of this
Agreement, and (iv) the entering into this Agreement does not violate any provision of
any other Agreement to which said party is bound.
•
7
• •
IN WITNESS WHEREOF, the parties have executed and entered into this Agreement
for Contract Services as of the date first set forth above.
CITY OF S - 1 CH CONTRACTOR
By: /i ir By: CO
Its: /Cit ManaTer Its: Chris Christ , President
Attest: BY:. 1 ■EsviL -
Its: Albert Hernande�Jr.
C
lerk Senior Vice Prtident
APPROVED AS TO FORM:
B
Its: City Attorney
8
• •
ATTACHMENT 1
SCHEDULE OF COMPENSATION
9
, ..
. ; • •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650-2201
CONTRACTORS LIC. #273024 562 / 864-6566
FAX 562 / 864-6052
August 9, 2001
a'
r kz4k1/4.,
g \\
4 10...
I %-.N
City of Sea !peach \-\,
1776 Adolfo !Lopez Driv e. '4
Seal Beach,Ca 90740
■i %. 4,
Attention: * .11
Mr. PaultGiera
.3 c
Reference: Labor And:Eaniciment Rates
I 1.4
,
Per your request we have attached a cotiyot our standard Labor and Equipment Rates
for your review K
. '41,:kPk
5. -.1 - - Nt r ig,
We look forWard to working with you on futures:prOlects that you may have. If you should have
Um' t.0... „Aki:
any questions regarding this letter please do noKtiesitate to call.
..,.....7 -'..
..S..
Sincerely,
.. ...
Doty Bros:Equipment Co
,„.......
._,m,olktzk
,,, ,:: z.-•
y
s.:. .
,....;.. ,...
..„-..„:„,,,
Sc ' = ,,.,.- --.
tratg-1..t.,
qt- f-pw.e toe_
;f-
File:sealbchsd "-X4 - ff,,,„ :..:. • I g -""W
., ..,..„: 44...",,........„•.,...„.„ .,0H---,1 --.7 - . ii!!,:. g .
V . -- .....<- ; 04:ki.tr , Atitg..;
t , -- - -4-1::,1,i-,ii ra,-; sti...-L..—..,,tc44 A. a •AT!..-F- :j
' VCV * NZ:. ce:&1;:t•it '' a' A.1:14,r -,..
,..... •,- — ,,,,--- _...-,..,,r:- - . ..;;:::,., i
„.: .--.F--
...',Ke,,,,,,i,...-iml-g.,..•',.- . .,,zi,
7 •lw,-::: ,,
,..,..
Aeis' I krti iirt. f4
,......, ..,......... .
-- -,.!., r - .4 :4_,-- Jr....,...,_:.i- . ...?,-.:-.44,..x. r• • _
FAT ..Viii. 1 i';,,,M!..T- •=4 AA" dOlss...
1z .
,:gueLL"' w ,.. . ,e
,‘.,...\7- , 5 '..4.-x- -
S-' -4,...1.-
WsZAT,r0- llit--A.-P2A,,,g
P .',7--• ;, - -- - ---'17kee-54----z-.7.1*.iVia-*
v-Z ,.:4, kr Iw- 4
4 -, ,....-. -I „1/4
-- ....__,
; --..t.,,c.,
-:,..
ss19.,
H
■ 39 C.A.
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
• FAX 562 / 864 -6052
LABOR RATE SCHEDULES
TRADE EFFECTIVE DATE
CARPENTERS JULY 1, 2001
LABORERS JULY 1, 2001
CEMENT MASONS JULY 1, 2001
TEAMSTERS JULY 1, 2001
OPERATING ENGINEERS JULY 1, 2000
UTILITY PIPE TRADES .. . JANUARY 1, 1999
INDUSTRIAL & GENERAL PIPEFITTING JULY 1, 2001
U A PLUMBERS & FITTERS - SHORTLINE...JANUARY 1, 2001
48,3\ CA
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864-6566
SCHEDULE OF LABOR RATES FAX 562 / 864 -6052
CARPENTERS - EFFECTIVE JULY 1, 2001
INVOICE CHARGES
UNION BASE STRAIGHT PREMIUM DOUBLE
CODE CLASSIFICATION PAY TIME TIME TIME
45 CARPENTER FOREMAN 29.25 58.20 82.59 106.99
45 CARPENTER 27.75 55.69 78.84 101.98
45 MILLWRIGHT FOREMAN 29.75 59.03 83.94 108.65
45 MILLWRIGHT 28.25 56.53 80.09 103.65
45 SHINGLER 27.88 55.91 79.16 102.42
SUBSISTANCE PER DAY
CARPENTERS 30.00
MILLWRIGHTS 30.00
BENEFITS:
VACATION /SUPP. DUES.... 2.82
HEALTH & WELFARE 2.30
PENSION 1.01
APPRENTICE TRAINING .30
INDUSTRY FUND .05
CONTRACT ADMIN. FUND .05
COOPERATION COMMITTEE .21
VACATION PAY NOT INCLUDED IN BASE PAY
OVERTIME RATES: ALL OVERTIME MONDAY THROUGH SATURDAY SHALL BE AT
THE RATE OF ONE AND ONE -HALF (1 -1/2) THE REGULAR STRAIGHT TIME
HOURLY RATE.
ALL HOURS WORKED ON SUNDAY OR HOLIDAYS SHALL BE PAID AT DOUBLE
THE STRAIGHT TIME HOURLY RATE.
C A
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
FAX 562 / 864 -6052
SCHEDULE OF LABOR RATES
LABORERS - EFFECTIVE JULY 1, 2001
INVOICE CHARGES
UNION BASE STRAIGHT PREMIUM DOUBLE
CODE PAY TIME TIME TIME
50 FOREMAN 23.41 52.34 71.86 91.39
50 GROUP 1 - LABORERS 19.46 45.75 61.98 78.21
50 GROUP 2 - WRAPPER TO 6" 19.96 46.58 63.23 79.88
50 GROUP 3 - PTO /WRAPPER 6" & OVER 20.46 47.42 64.48 81.54
50 GROUP 4 - PIPE LAYER, C/S 21.91 49.84 68.11 86.38
50 GROUP 5 - BLASTER 22.16 50.25 68.73 87.22
VACATION PAY 2.55
HEALTH & WELFARE 3.10
PENSION 3.81
TRAINING & RETRAINING .35
INDUSTRY FUND .06
CENTER FOR CONTRACT COMPLIANCE .15
CONTRACT COMPLIANCE .06
SUBSISTANCE - 30.00 /DAY
VACATION PAY NOT INCLUDED IN BASE PAY
OVERTIME RATES: ALL HOURS OUTSIDE REGULARLY CONSTITUTED SHIFT SHALL BE TIME AND
ONE HALF.
SUNDAYS AND HOLIDAYS SHALL BE AT DOUBLE TIME
WAGE SCALES ARE IN ACCORDANCE WITH ASSOCIATED GENERAL CONTRACTORS MASTER LABOR
AGREEMENT AND ARE SUBJECT TO CHANGE WITHOUT NOTICE.
4 1§i ' a
CA
•
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
SCHEDULE OF LABOR RATES FAX 562 / 864 -6052
CEMENT MASONS AGREEMENT - EFFECTIVE July 1, 2001
INVOICE CHARGES
UNION CLASSIFICATION BASE STRAIGHT PREMIUM DOUBLE
CODE PAY TIME TIME TIME
55 FOREMAN 23.81 56.59 76.45 96.30
55 JOURNEYMAN 22.31 54.09 72.69 91.30
55 MACHINE OPERATOR 22.56 54.50 73.32 92.13
COMMERCIAL
VACATION & SUPPL. DUES
HEALTH & WELFARE 3.75
PENSION 4.43
APPRENTICE TRAINING .27
INDUSTRIAL FUND .06
CONTRACT COMPLIANCE .06
SUBSISTANCE _.. 30.00 /DAY
VACATION PAY NOT INCLUDED IN BASE PAY
OVERTIME RATES: FIRST THREE HOURS OUTSIDE THE REGULAR SHIFT WILL BE AT
TIME AND ONE HALF. ALL ADDITIONAL HOURS AT DOUBLE TIME
WAGE SCALES ARE IN ACCORDANCE WITH ASSOCIATED GENERAL CONTRACTORS MASTER
LABOR AGREEMENT, AND ARE SUBJECT TO CHANGE WITHOUT NOTICE.
411'0
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
SCHEDULE OF LABOR RATES FAX 562 / 864 -6052
TRUCK DRIVERS - EFFECTIVE JULY 1, 2001
INVOICE CHARGES
UNION BASE STRAIGHT PREMIUM DOUBLE
CODE CLASSIFICATION PAY TIME TIME TIME
60 FOREMAN 23.35 55.18 74.65 94.12
60 WORKING CONSTRUCTION 21.85 52.68 70.90 89.12
60 LO -BED 23.85 56.01 75.90 95.79
60 4 OR MORE AXLE 21.97 52.87 71.20 89.52
VACATION PAY 2.60
HEALTH & WELFARE 4.57
PENSION 4.80 -
TRAINING & UPGRADING FUND .42
INDUSTRY FUND .06
CONTRACT COMPLIANCE .06
SUBSISTANCE 30.00 /DAY
VACATION PAY NOT INCLUDED IN BASE PAY
OVERTIME RATES: ALL HOURS OUTSIDE REGULARLY CONSTITUTED SHIFT SHALL BE TIME
AND ONE HALF; SUNDAYS AND HOLIDAYS SHALL BE AT DOUBLE TIME.
WAGE SCALES ARE IN ACCORDANCE WITH ASSOCIATED GENERAL CONTRACTORS MASTER
LABOR AGREEMENT AND ARE SUBJECT TO CHANGE WITHOUT NOTICE.
414
to
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
FAX 562 / 864 -6052
SCHEDULE OF LABOR RATES
OPERATING ENGINEER - EFFECTIVE JULY 1, 2000
INVOICE CHARGES
UNION CLASSIFICATION BASE STRAIGHT PREMIUM DOUBLE
CODE PAY TIME TIME TIME
65 GENERAL FOREMAN 31.54 66.95 93.26 119.56
65 FOREMAN 30.04 64.45 89.51 114.56
65 GROUP 1 OILER 26.25 58.13 80.02 101.92
65 GROUP 2 OILER 27.03 59.43 81.98 104.52
65 GROUP 8- UNIV. OPERATOR 28.54 61.95 85.75 109.56
65 GROUP 10- MOTOR PATROL OPR /. 28.76 62.32 86.30 110.29
HEAVY DUTY MECH
65 GROUP 8- CRANE OPERATOR 28.83 62.43 86.48 110.52
VACATION PAY 2.50
HEALTH & WELFARE 4.05
PENSION 3.75
APPR. TRAINING & RETRAINING .55
INDUSTRY FUND .05
CONTRACT COMPLIANCE .05
CONTRACT ADMIN. FUND .03
SUBSISTANCE 24.00 /DAY
VACATION PAY NOT INCLUDED IN BASE PAY.
OVERTIME RATES: FIRST FOUR (4) HOURS OUTSIDE REGULAR SHIFT, AND FIRST TWELVE
(12) HOURS ON SATURDAY IS TIME AND ONE HALF; ALL ADDITIONAL
HOURS AT DOUBLE TIME EXCEPT HOLIDAYS WHICH ARE AT TRIPLE TIME.
WAGE SCALES ARE IN ACCORDANCE WITH ASSOCIATED GENERAL CONTRACTORS MASTER
LABOR AGREEMENT AND OTHER NEGOTIATED AGREEMENTS, AND ARE SUBJECT TO CHANGE
WITHOUT NOTICE.
_, CA
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
FAX 562 / 864 -6052
SCHEDULE OF LABOR RATES
UTILITY PIPE TRADES - EFFECTIVE JANUARY 1, 1999
INVOICE CHARGES
UNION CLASSIFICATION BASE STRAIGHT PREMIUM DOUBLE
CODE PAY TIME TIME TIME
70 GENERAL FOREMAN 27.74 59.02 83.41 106.54
70 FOREMAN 26.74 57.35 80.90 103.21
70 - FITTER 22.99 51.10 71.52 90.70
VACATION PAY 1.50
HEALTH & WELFARE 3.77
PENSION 3.84
APPR. TRAINING & RETRAINING .10
DUES .54
RET. CHRISTMAS .19
P I P E .10
SUBSISTANCE..OVER 40 MILES 24.00 /DAY
VACATION PAY NOT INCLUDED IN PAY RATE.
VACATION PAY NOT APPLICABLE OVERTIME RATES.
OVERTIME RATES: TIME AND ONE HALF EXCEPT SUNDAYS AND HOLIDAYS WHICH ARE
DOUBLE TIME.
WAGE SCALES ARE IN ACCORDANCE WITH ASSOCIATED GENERAL CONTRACTORS MASTER LABOF
AGREEMENT AND ARE SUBJECT TO CHANGE WITHOUT NOTICE.
ale
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
SCHEDULE OF LABOR RATES FAX 562 / 864 -6052
INDUSTRIAL & GENERAL PIPEFITTING - EFFECTIVE JULY 1, 2001
(L.A. /ORANGE COUNTY - LOCAL 250)
DISTRICT COUNCIL 16
LOCAL 250, 364, 398
UNION CLASSIFICATION BASE STRAIGHT PREMIUM DOUBLE
CODE PAY TIME TIME TIME
74 GENERAL FOREMAN 32.48 72.12 102.16 129.25
75 INDUSTRIAL FOREMAN 29.90 67.41 95.10 120.04
76 WELDER, FITTER 26.03 60.34 84.49 106.20
BENEFITS BASED ON HOURS WORKED
CLASSIFICATION H & W VAC.PAY PENSION APP. TRNG.
GENERAL FOREMAN 3.77 3.54 3.09 .43
INDUSTRIAL FOREMAN 3.77 3.30 3.09 .43
WELDER, FITTER 3.77 2.93 3.09 .43
PIPE NAT'L PEN RET. X -MAS
".20 1.50 .50
*VACATION PAY IS CALCULATED AT PREMIUM TIME FOR ALL PREMIUM TIME HOURS
WORKED.
SUBSISTENCE: OVER 50 AIR MILES $28.00 PER DAY
VACATION PAY NOT INCLUDED IN BASE RATE.
PREMIUM PAY: 1ST FOUR (4) HOURS IN EXCESS OF 8 AND 12 HOURS SATURDAY -
TIME AND ONE HALF. ALL OTHER • HOURS AT DOUBLE TIME.
WAGE SCALES ARE IN ACCORDANCE WITH ASSOCIATED GENERAL CONTRACTORS MASTER
LABOR AGREEMENT AND ARE SUBJECT TO CHANGE WITHOUT NOTICE.
=3 CA.
• •
DOTY BROS. EQUIPMENT CO.
PIPELINE CONTRACTORS 11232 E. FIRESTONE BLVD. • NORWALK, CA 90650 -2201
CONTRACTORS LIC. #273024 562 / 864 -6566
FAX 562 / 864 -6052
SCHEDULE OF LABOR RATES
U A PLUMBERS & FI1rlRS - SHORTLINE - EFFECTIVE JANUARY 1, 2001
INVOICE CHARGES
UNION CLASSIFICATION BASE STRAIGHT PREMIUM DOUBLE
CODE PAY TIME - TIME TIME
82 GENERAL FOREMAN 32.94 71.98 102.26 129.73
81 FOREMAN 28.99 65.39 92.38 116.55
80 WELDER / FITTER 26.21 60.82 85.52 107.50
79 WELDER HELPER 16.65 37.96 52.68 66.57
JOURNEYMAN HELPER -
VACATION PAY 3.37/3.27 1.00
HEALTH & WELFARE 3.77 3.77
PENSION 3.20 1.96
APPR. TRAINING .30 .10
WELDER CERTIFICATION .10 .02
SUPPL. DUES .54 .25
RETIREMENT /CHRISTMAS .35 .0
. NATIONAL PENSION 1.25 1.00
SUBSISTENCE AS REQUIRED
VACATION PAY AND SUPPLEMENTAL DUES NOT INCLUDED IN PAY RATE.
VACATION PAY PAID AT APPLICABLE OVERTIME RATES.
OVERTIME RATES: TIME AND ONE HALF EXCEPT SUNDAYS AND HOLIDAYS WHICH ARE DOUBLE
TIME.
WAGE SCALES ARE IN ACCORDANCE WITH ASSOCIATED GENERAL CONTRACTORS MASTER LABOR
AGREEMENT AND ARE SUBJECT TO CHANGE WITHOUT NOTICE.
•
•
a •
•
DOTY BROS. EQUIPMENT CO.
EQUIPMENT LIST RATE CODE A .'EFFECTIVE 01/1/97
REV. 9/7/99
NO. HOURLY RATE
BACK HOES
CASE 580 /JD 310 34.00
JD 710 40.00
JD 690B (TRACK MOUNTED) 55.00
CAT 235 (TRACK MOUNTED) 100.00
CAT 300 (TRACK MOUNTED) 93.00
COMPACTION EQUIPMENT
ARROW (HYDRO HAMMER) 40.00
54" SINGLE DRUM VIBRATING SHEEPS FOOT 42.00
COMPRESSORS W /90 LB BREAKER, CLAY SPADE & TAMPER
125 -185 CFM 16.00
CRANES
SWING CRANE TRACK MOUNTED 23.50
BOOM TRUCK UP TO 8 TONS 25.00
BOOM TRUCK 10 TO 11 TON 40.00
BOOM TRUCK 14 TON, 3 AXL 45.00
GROVE CRANE 15 - 18 TON RT - (OR EQUIVALENT) 52.00
GROVE CRANE 28 TON 62.00
FORKLIFTS
6,000 # 18.00
20,000 # 30.00
LOADERS
SKIPLOADER CASE 580 /MF4AE 22.00
930 CAT RUBBER TIRE LOADER 40.00
950 CAT RUBBER TIRE LOADER 50.00
950E CAT RUBBER TIRE LOADER 60.00
966C CAT RUBBER TIRE LOADER - 55.00
i ROAD EQUIPMENT
CAT MODEL 12 - GRADER 53.00
9 VIBRATOR ROLLER, 1 TON HAND (WALK BEHIND) 20.00
ROLLER (RIDEON) 25.00
FLASHING ARROW 4 HR. MIN. 15.00
' TILT TRAILER /CABLE DOLLY 10.00
BITELLI COLD PLANER 200.00 /4 HR MIN
SIDEBOOMS /DOZERS
• JD 450 SIDEBOOM• 35.00
CAT D -6 SIDEBOOM /DOZER 45.00
CAT D -7 SIDEBOOM 52.00
CAT 572 SIDEBOOM 60.00
CAT D -4 /JD 450 DOZER - 35.00
CAT D -6 DOZER 68.00
Page 1 of 4
•
•
• • •
DOTY BROS. EQUIPMENT CO.
HOURLY RATE
NO. TRENCHERS * **
PARSONS 133 26.00
BUCKEYE 410 30.00
PARSONS 155 31.00
BUCKEYE 120 37.00
** *TEETH ADDITIONAL
TRUCKS
PICKUPS, 1/2 - 3/4 TON 7.50
TRUCK, 1 TON (SERVICE OR 4 WD PICKUP) 10.00
TRUCK, 2 -3 TON (FLATBED, A /FRAME, UTILITY,HOE MOVER) 14.00
HIGHWAY TRACTOR W /TRAILER (LOWBED) + MOVE PERMIT FEES 35.00
DUMP TRUCK 5 YARD (BOBTAIL OR FLAT BED) 14.00:
DUMP TRUCK 8 YARD 20.00
40,000# TRAILER 15.00
DUMP TRUCK, 10 YARD (10 WHEEL) 22.00
LOWSIDE END DUMP 26.00
WATER TRUCK (1500 -2200 GALS.) 25.00
WATER TRUCK (3500 GALS.) 30.00
WELDERS
200 AMF, TRAILER OR SKID MOUNTED 12.00
200 AMF, TRUCK MOUNTED 17.00
.! MISCELLANEOUS
1178 BORING MACHINE 1 -3/.4" 15.00
1177 BORING MACHINE 3 -1/2" 20.00
1520 BORING MACHINE 4" - 8" 25.00 4 HR MIN
854 BORE MOTOR 10.00
CEMENT SAW (SMALL) 20.00
CEMENT SAW (MEDIUM) 25.00
CEMENT SAW (LARGE) 30.00
846 CHAIN LINK FENCE PANELS _ 24.00 /EA. /JOB
847 CHAIN LINK FENCE
•
2.00 /FT. /JOB
,1085 POWER BROOM (TRACTOR MOUNTED) 20.00
(820 TAPPING MACHINE (WATERLINES UP-TO 2: 20.00 /INCH
qtt 828 TAPPING MACHINE (WATERLINES 3" TO 12 ") 20.00 /INCH
1082 BENDING MACHINE 6')-20" + SHOES & FREIGHT 400.00 /DAY
•
,MISCELLANEOUS DAILY RATE
879 BARRICADES /DELINEATORS /CONES 1.00
PLYWOOD 1/3 REPLACEMENT COST
SHORING LUMBER 8 "X8 "X8' 1/3 REPLACEMENT COST
SHORING LUMBER 3 "X12 "X14' 1/3 REPLACEMENT COST
851 BEVELING MACH. OR EXT. LINEUP CLAMP & CUTTERS 8 " -14" 25.00
839 BEVELING MACH. OR EXT. LINEUP CLAMP & CUTTERS 16 " -36" 50.00
836 BUFFERS & GRINDERS - 25.00
6886 CEMENT MIXER 40.00
Page 2 of 4
DOTY EROS. EQUIPMENT CO.
MISCELLANEOUS DAILY RATE
850 CHAIN SAW 50.00
890 CLEANING BALL 10.00
1535 COMPACTOR (NERVOUS TURTLE) 150.00
891 CONCRETE VIBRATOR 40.00
882 CONSTRUCTION SIGNS 4.00
878 CROSSING PLATES 6.25
810 CUT -OFF SAW 50.00
837 DEAD :4EIGHT TESTER 60.00
EMULSION POT SPRAYER 60.00
FLOODLIGHT TRAILER (MERCURY VAPOR LIGHTS) 125.00
841 FLOW LINER 25.00
1807 GENERATOR (3.5 - 5 KW) 50.00
842 HILTI GUN 50.00
838 HOLIDAY DETECTOR 25.00
875 LADDER 10.00
LIGHT STAND 15.00
840 MANHOLE BLOWER 40.00
MOBILE PHONE - PLUS CALLS 7.50
843 PIPE LOCATOR 25.00
1834 TESTING TABLE 60.00
853 POWER THREADER 85.00
835 SKILL SAW 20.00
827 TAP MACHINE - T.D. WILLIAMSON (UP TO 3 ") 100.00
862 TAR POT 50.00
892 TEST PLUG 10.00
TEST PUMP - 200# 80.00
1815 TEST PUMP - 200 - 400# SPRAGUE 125.00
6818 TEST PUMP - 5000# TRAILER MTD 175.00
845 TRANSIT - LEVEL 25.00
TRANSIT - LASER 75.00
TRANSIT - THEOLITE 35.00
877 TRENCH JACK (SCREW) 4.00
UTILITY VEHICLE (NON -HWY.) 50.00
,,1861 VIBRATOR PLATE (24 ") 85.00
(1860 WACKER TAMPER 85.00
893 WALKIE TALKIES / SET OF 2 25.00
1 871 WATER HOSE 1- 1 /2 ".X 50' 6.00
872 WATER HOSE 2 -1/2" X 50' 7.50
183; WATER PUMP 2" PORTABLE 50.00
1832 WATER PUMP 3" PORTABLE 75.00
AIR TOOLS DAILY RATE
870 AIR HOSE 3/4" X 50' 8.00
868 CHIPPING GUN 35.00*
866 CLAY SPADE • 35.00*
864 IMPACT WRENCH 1" 35.00
Page 3 of 4
• •
•
DOTY BROS. EQUIPMENT CO
AIR TOOLS (CONT'D.) DAILY RATE
858 JACKHAMMER 35.00*
867 PAVEMENT BREAKER 35.00*
869 RIPPING GUN 35.00
865 ROCK JACK 35.00*
852 ROTARY HAMMER 50.00*
859 TAMPER 35.00
*PLUS STEEL
SAFETY AND HAZMAT EQUIPMENT DAILY RATE
844 EXPLOSIMETER 50.00
914 GAS /OXY MONITOR 100.00
H2S MONITOR 15.00
913 TRIPOD W /HARNESS 100.00
916 SCBA 40.00
912 NOMAX SUITS 6.50
918 ESCAPE AIR PACK 25.00
•
•
Page 4 of 4
•
•
•
•