HomeMy WebLinkAbout*AGMT - P & D Consultants (EIR Consultants) .��LLQ Gil 64r 2
t VW
-
ti/:/ yr
4„
AGREEMENT FOR CONTRACT SERVICES
THIS AGREE : NT FOR ONTRACT SERVICES (the "Agreement ") is made and entered
into as of � � , 199 7 by and between the CITY OF SEAL
BEACH, a muni' 'pa ' corporation ( "City ") and pc Coiv3'uj r u
( "Contractor ").
RECITALS
WHEREAS, City desires to employ the services of several consultants to provide
on -going professional services regarding environmental assessment in accordance with the
provisions of the California Environmental Qulaity Act (CEQA) and the Local CEQA Guidelines of
the CITY; and
WHEREAS, the California Environmental Quality Act, the State EIR Guidelines,
and City's local EIR Guidelines may require the preparation of a Negative Declaration (hereinafter
"Neg. Dec." ) or an Environmental Impact Report (hereinafter "EIR ") prior to the City's decision on
a project; and
WHEREAS, Contractor represents that it is able to prepare the Neg. Dec. or EIR
in conformance with all applicable laws and guidelines;
NOW, THEREFORE, the parties agree that the term of this Agreement shall be
for three (3) years from the day and year first above stated.
IN WITNESS WHEREOF, the parties have executed and entered into this
Agreement for Contract Services as of the date first set forth above.
CITY OF S'AL B_ ACH CONTRA OR
BY: ►_ /. : _ By:
Its: City Manager Its: P
B F .
;, �/ Its: Y' cc 2ebtrdQ T
City erk
APPROVED AS TO FORM: o
•
Quinn Barrow
City Attorney
C:1My Documents\FORMS\EIR Services Agrecnxnt.DOC\LW\O6 -3O -97
E1R Services Agreement
City of Scal Beach and
July, 1997
PART I
FUNDAMENTAL PROJECT TERMS
A. Location of Subject Project:
•
B. Description of Services /Goods to be Provided:
•
•
C. Term: Unless terminated earlier as set forth in this Agreement, the services shall
commence on , 199 ( "Commencement Date ") and the term
of this Agreement shall continue through ,199
D. Party Representatives:
D.1. The City designates the following person/officer to act on City's behalf:
D.2. The Contractor designates the following person to act on Contractor's behalf:
E. Notices: Contractor shall deliver all notices and other writings required to be delivered
under this Agreement to City at the address set forth in Part II ( "General Provisions ").
City shall deliver all notices and other writings required to be delivered to Contractor at the
address set forth following Contractor's signature below.
F. Attachments: This Agreement incorporates by reference the following Attachments to this
Agreement:
F.1. Part I: Fundamental Project Terms
F.2. Part I1: General Provisions
F.3. Part III: Special Provisions
F.4. • Part IV: Scope of Work.
F.5. Part V: Budget
EIR Services Agreement.DOC 2
E1R Services Agreement
City o/jSeal Beach and
July, 1997
G. Integration: This Agreement represents the entire understanding of City and Contractor as
to those matters contained herein. No prior oral or written understanding shall be of any
force or effect with regard to those matters covered by this Agreement. This Agreement
supersedes and cancels any and all previous negotiations, arrangements, agreements, and
understandings, if any, between the parties, and none shall be used to interpret this
Agreement. This Agreement may only be amended by the mutual consent of the parties by
an instrument in writing.
IN WITNESS WHEREOF, the parties have executed and entered into this
Fundamental Project Term as of the date first set forth above in Paragraph C.
CITY OF SEAL BEACH CONTRA TOR
By: By:
Its: Its:
• Attest: By:.
Its:
City Clerk
APPROVED AS TO FORM: Contractor Information
Richards, Watson & Gershon Address for Notices and Payments:
Quinn Barrow
City Attorney
Attn:
• Telephone Number:
•
FAX Nuniber:
EIR Services Agreement.DOC 3
• • E1R Services Agreement
City of Seal Beads and
July, 1997
PART II
GENERAL PROVISIONS
SECTION ONE: SERVICES OF CONTRACTOR
1.1 Scope of Work. Contractor shall provide the goods and/or services shown on Part IV
hereto ( "Scope of Work "). If this Agreement is for the provision of goods, supplies,
equipment or personal property, the terms "services" and "work" shall include the
provision (and, if designated in the Scope of Work, the installation) of such goods,
supplies, equipment or personal property.
1.2 Instructions from City. In the performance of this Agreement, Contractor shall
report to and receive instructions from City's Representative designated in Paragraph
D.1 of Part I ( "Fundamental Terms ") of this Agreement. Tasks or services other than
those specifically described in Part IV ( "Scope of Work ") shall not be performed
without the prior written approval of City's Representative.
1.3 Additional Services. City shall have the right at any time during the performance of
the services, without invalidating this Agreement, to, order extra work or make changes
by altering, adding to, or deducting from said work. No such work shall be undertaken
unless a written order is first given by City to Contractor, incorporating therein any
adjustment in (i) the Budget, and /or (ii) the time to perform this Agreement, which
adjustments are subject to the written approval of Contractor.
1.4 Standard of Performance. Contractor agrees that all serviees shall be performed in a
competent, professional, and satisfactory manner in accordance with the standards
prevalent in the industry, and that all goods, materials, equipment or personal property
included within the services herein shall be of good quality, fit for the purpose intended.
1.5 Performance to Satisfaction of City. Contractor agrees to perform all work to the
satisfaction of City within the time specitied. If Contractor's work is not satisfactory in
the opinion of City's designated representative, City has the right to take appropriate
action, including but not limited to any or all of the following: (i) meeting with
Contractor to review the quality of the work and resolve matters of concern; (ii)
requiring Contractor to repeat or correct the work at no additional fee until it is
satisfactory; (iii) suspending the delivery of new or additional work to Contractor for
an indefinite time; (iv) withholding, payment; and (v) terminating this Agreement as
hereinafter set forth. City's options set forth herein are non - exclusive, and are in
addition to any remedy available at law to City.
1.6 Familiarity with Work. By executing the Agreement, Contractor warrants that
Contractor (i) has thoroughly investigated and considered the Scope of Work to be
EIR Services Ageement.DOC 4
• • E1R Services Agreement
City of Seal Beach and
July. 1997
performed, (ii) has carefully considered how the services should be performed, and (iii)
fully understands the facilities, difficulties, and restrictions attending performance of the
services under the Agreement. if the services involve work upon any site, Contractor
warrants that Contractor has or will investigate the site and is or will be fully
acquainted with the conditions there existing, prior to commencement of services
hereunder. Should the Contractor discover any conditions, including any latent or
unknown conditions, which will materially affect the performance of the services
hereunder, Contractor shall immediately inform City of such fact and shall not proceed
except at Contractor's risk until written instructions are received from City's
Representative.
1.7 Prohibition Against Subcontracting or Assignment. Contractor shall not contract
with any other entity to perform in whole or in part the services required hereunder
without the express written approval of City. In addition, neither the Agreement nor
any interest herein may be transferred, assigned, conveyed, hypothecated, or
encumbered voluntarily or by operation of law, whether for the benefit of creditors or
otherwise, without the prior written approval of City. In the event of any unapproved
transfer, including in any bankruptcy proceeding, City may void the Agreement at City's
option in its sole and absolute discretion. No approved transfer shall release any surety
of Contractor of any liability hereunder without the express consent of City.
1.8 • Compensation. Contractor shall be compensated in accordance with the terms of Part
V ( "Budget "). Included in the Budget are all ordinary and overhead expenses incurred
by Contractor and its agents and employees, including meetings with City
representatives, and incidental costs incurred in performing under this Agreement.
SECTION TWO: INSURANCE AND INDEMNIFICATION
2.1 Insurance.
2.1.1 Type of Insurance Required. Contractor shall procure and maintain, at
its cost and for the duration of this Agreement, comprehensive general liability and
property damage insurance, including automobile and excess liability insurance, against
all claims for injuries against persons or damages to property which may arise from or
in connection with the performance of the work hereunder by Contractor, its agents,
representatives, employees, and /or subcontractors. . It shall be the sole and exclusive
duty of Contractor to ensure that its sub - contractors have complied with the insurance
requirements set forth herein, and that evidence of such compliance is provided to City
within the time limits specified in Section 2.1.6.
2.1.2 Amount of Insurance Required. The amounts of insurance required
hereunder shall be as set forth in Part I11 ( "Special Provisions ") of this Agreement.
2.1.3 General Requirements. All of Contractor's and its sub - contractor's
policies of insurance shall:
EIR Services Agreement.DOC 5
• •
E1R Services Agreement
City of Seal Beach and
July, 1997
2.1.3.1 Name City, its officers, officials, employees, agents,
representatives and volunteers (collectively hereinafter "City and City
Personnel ") as additional insureds and contain no special limitations on the
scope of protection afforded to City and City Personnel;
2.1.3.2 Be primary insurance and shall provide that any insurance or
self - insurance maintained by City or City Personnel shall be in excess of
Contractor's insurance and shall not contribute with it;
2.1.3.3 Be "occurrence" rather than "claims made" insurance;
2.1.3.4 Apply separately to each insured against whom claim is made or
suit is brought, except with respect to the limits of the insurer's liability;
2.1.3.5 Be endorsed to state that the insurer shall waive all rights of
subrogation against City and City Personnel; and
2.1.3.6 Be written by good and solvent insurer(s) admitted to do
business in the State of California and acceptable to City.
2.1.4 Deductibles. Any deductibles or self - insured retentions must be declared
to and approved by City prior to the execution of this Agreement by City.
2.1.5 Notice of Policy Changes. Each such insurance policy shall be endorsed
to state that coverage shall not be suspended, voided, cancelled, reduced in coverage or
in limits, non - renewed, or materially changed for any reason, without thirty (30) days
prior written notice thereof given by the insurer to City by U.S. mail, certified, or by
personal delivery. In addition to such notice provided to City by the insurer,
Contractor shall also provide City with thirty (30) days prior written notice, by certified
mail, return receipt requested, of the suspension, voiding, cancellation, reduction in
coverage or in limits, non - renewal, or material change for any reason, of any such
insurance policy or policies.
2.1.6 Evidence of Coverage. Contractor shalf furnish City with certificates of
insurance demonstrating the coverage required by this Agreement which shall be
received and approved by City not less than five (5) working days before work
commences. The duplicate originals and original endorsements for each insurance
policy shall be signed by a person authorized by that insurer to bind coverage on its
behalf. The procuring of such insurance or the delivery of duplicate originals and
endorsements evidencing the same shall not be construed as a limitation on Contractor's
obligation to indemnify City and City Personnel.
EIR Services AgreernentDOC 6
• EIR Services Agreement
City of Seal Beach and
July, 1997
2.1.7 Workers Compensation Insurance.
2.1.7.1 Contractor shall, to the extent required by the California Labor
Code, provide Workers' Compensation Insurance for the protection of
Contractor's employees. Contractor shall file, within the time limits specified in
Section 2.1.6 of this Agreement, a certificate of insurance which evidences that
Contractor is in compliance with said Worker's Compensation Insurance
requirement.
2.1.7.2 For any Workers' Compensation and Employer's Liability
Coverage, the insurer shall. agree to waive all rights of subrogation against the
City and City Personnel arising from work performed by the Contractor for the
City.
2.1.7.3 Contractor shall require all subcontractors similarly to provide
such Workers' Compensation Insurance and certificates of insurance for their
respective employees.
2.1.7.4 In the event Contractor has no employees requiring Contractor
to provide Workers' Compensation Insurance, Contractor shall so certify to
City in writing prior to City's execution of this Agreement. City and City
Personnel shall not be responsible for any claims in law or equity occasioned by
failure of the Contractor to comply with this section or with the provisions of
law relating to Workers' Compensation.
2.2 Indemnification. Contractor shall indemnify, defend, and hold City and City
Personnel harmless from and against any and all actions, claims, demands, judgements,
attomey's fees, costs, damage to persons or property, penalties, obligations, expenses
or liabilities that may be asserted or claimed by any person or entity arising out of the
willful or negligent acts, errors, or omissions of Contractor, its employees, agents,
representatives or subcontractors in the performanee of any tasks or services for or on
behalf of City, whether or not there is concurrent active or passive negligence on the
part of City and /or City Personnel; provided, however, that the Contractor shall not be
required to indemnify, defend or hold harmless City or City Personnel against claims
arising from the sole active negligence or willful misconduct of City or City Personnel.
In connection therewith:
2.2.1 Contractor shall defend, with Counsel acceptable to City, any action or
actions filed in connection with any such claimed damage, injury, penalty, obligation or
liability, and shall pay all costs and expenses, including attorney's fees, inccurred
therewith.
2.2.2 In the event City and /or any City Personnel is made a party to any action
or proceeding filed or prosecuted for any such claimed damage, injury, penalty,
obligation or liability, Contractor shall defend City and pay to City any and all costs and
EIR Services Agreement.DOC 7
•
EIR Services Agreement
City of Seal Beach and
July, 1997
expenses incurred by City in such action or proceeding, together with reasonable
attorney's fees and expert witness fees.
SECTION THREE: LEGAL RELATIONS AND RESPONSIBILITIES
3.1 Compliance with Laws. Contractor shall keep fully informed of all State and Federal
laws and County and Municipal ordinances and regulations which in any manner affect
those employed by it or in any way affect the performance of services pursuant to this
Agreement. Contractor shall at all times observe and comply with all such laws,
ordinances, and regulations and shall be responsible for the compliance of all work and
services performed by or on behalf of Contractor. Each and every provision required
by law to be inserted into this Agreement shall be deemed to be inserted, and this
Agreement shall be read and enforced as though they were included.
3.2 Independent Contractor. Contractor shall perform all services required herein as an
independent contractor of City and shall remain at all times as to City a wholly
independent contractor. City shall not in any way or for any purpose become or be
deemed to be a partner or employer of Contractor in its business or otherwise, or a
joint venturer, or a member of any joint enterprise with Contractor. Contractor shall
not at any . time or in any manner represent that it or any of its agents or employees are
agents or employees of City. Neither Contractor nor any of Contractor's employees
shall, at any time, or in any way, be entitled to any sick leave, vacation, retirement, or
other fringe benefits from City; and neither Contractor nor any of its employees shall be
paid by City any wage or overtime benefit. City is under no obligation to withhold
State and Federal tax deductions from Contractor's compensation. Neither Contractor
nor any of Contractor's employees shall be included in the competitive service, have
any propeny right to any position, or any of the rights a City employee might otherwise
have in the event of termination of employment.
3.3 Covenant Against Discrimination. Contractor covenants for itself, its heirs,
executors, assigns, and all persons claiming under or through it, that there shall be no .
discrimination against any person on account of race, color, creed, relation, sex, marital
status, national origin, or ancestry, in the performance of this 'Agreement. Contractor
further covenants and agrees to comply with the terns of the Americans with
Disabilities Act of 1990 (42 U.S.C. §12101 et seq.) as the same may be amended from
time to time.
3.4 Use of Patented Materials. Contractor shall assume all costs arising from the use of
patented or copyrighted materials, including but not limited to equipment, devices,
processes, and software programs, used or incorporated in the services or work
performed by Contractor under this Agreement. Contractor shall indemnify, defend,
and save City harmless from any and all suits, actions or proceedings of every nature
for, or on account of, the use of any patented or copyrighted materials.
EIR Services Agreement.DOC 8
•
EIR Services Agreement
City of Seal Beach and
July. 1997
3.5 Licenses. Permits. Fees and Assessments. Contractor shall obtain and keep in effect
throughout this Agreement, at its sole cost and expense, all licenses, permits, and
approvals that may be required by law for the performance of the services required by
this Agreement including, without limitation, a City business license. Contractor shall
have the sole obligation to pay any fees, assessments, and taxes, plus applicable
penalties and interest, which may be imposed by law and arise from or are necessary for
the Contractor's performance of the services required by this Agreement, and shall
indemnify, defend, and hold harmless City against any such fees, assessments, taxes,
penalties, or interest levied, assessed, or imposed against Contractor thereunder.
3.6 Proprietary Information. All proprietary information developed specifically for City
by Contractor in connection with, or resulting from, this Agreement, including but not
limited to inventions, discoveries, improvements, copyrights, patents, maps, reports,
textual material, or software programs, but not including Contractor's underlying
materials, software, or know -how, shall be the sole and exclusive property of City, and
are confidential and shall not be made available to any person or entity without the
prior written approval of City. Contractor agrees that the compensation to be paid
pursuant to this Agreement includes adequate and sufficient compensation for any
proprietary information developed in connection with or resulting from the
performance of Contractor's services under this Agreement. Contractor further
understands and agrees that full disclosure of all proprietary information developed in
connection with, or resulting from, the performance of services by Contractor under
this Agreement shall be made to City, and that Contractor shall do all things necessary
and proper to perfect and maintain ownership of such proprietary information by City.
3.7 Retention of Funds. Contractor hereby authorizes City to deduct from any amount
payable to Contractor (whether arising out of this Agreement or otherwise) any
amounts the payment which may be in dispute or which are necessary to compensate
City in full or part for losses, costs, liabilities, or damages suffered by City, and all
amounts for which City may be liable to third parties, by reason of Contractor's
negligent acts, errors, or omissions, or willful misconduct, in pertorming or failing to
perform Contractor's obligations under this Agreement. City in its sole and absolute
discretion, may withhold from any payment due Contractor, without liability for
interest, an amount sufficient to cover such claim or any resulting lien. The failure of
City to exercise such right to deduct or withhold shall not affect the obligations of the
Contractor to insure and indemnify City as elsewhere provided herein, or act as a
waiver of Contractor's obligation to pay City any sums Contractor owes City.
3.8 Termination By City. City reserves the right to terminate this Agreement at any time,
with or without cause, upon written notice to Contractor. Upon receipt of any notice
of termination from City, Contractor shall immediately cease all services hereunder
except such as may be specifically approved in writing by City. Contractor shall be
entitled to compensation for all services rendered prior to receipt of City's notice of
termination and for any services authorized in writing by City thereafter. If termination
is due to the failure of Contractor to fulfill its obligations under this Agreement, City
may take over the work and prosecute the same to completion by contract or
EIR Services Ageement.DOC 9
• •
• EIR Services Agreement
City of Seal Beach and
July, 1997
otherwise, and Contractor shall be liable to the extent that the total cost for completion
of the services required hereunder, including costs incurred by City in retaining a
replacement contractor and similar expenses, exceeds the Budget .set forth in Part V
hereto.
3.9 Right to Stop Work: Termination By Contractor. Contractor shall have the right to
stop work only if City fails to timely make a payment required under the terms of the
Budget, at which point Contractor may suspend performance under this Agreement
after thirty (30) days' prior written notice to City. Contractor shall immediately cease
all services hereunder as of the date Contractor's notice of termination is sent to the
City. Contractor . shall be entitled to compensation for all services rendered prior to the
date notice of termination is sent to City and for any services authorized in writing by
City thereafter. If Contractor terminates this Agreement because of an error, omission,
or a fault of Contractor, or Contractor's willful misconduct, the terms of Section 3.8
relating to City's right to take over and finish the work and Contractor's liability
therefor shall apply.
3.10 Waiver. No delay or omission in the exercise of any right or remedy by a
nondefaulting party on any deault shall impair such right or remedy or be construed as
a waiver. A party's consent to or approval of any act by the other party requirine the
party's consent or approval shall not be deemed to waive or render unnecessary the
other party's consent to or approval of any subsequent act. Any waiver by either party
of any default must be in writing and shall not be a waiver of any other default
conceming the same or any other provision of this Agreement.
3.11 Legal Actions. The Municipal and Superior Courts of the State of Califomia in the
County of Orange shall have the exclusive jurisdiction of any litigation between the
parties arising out of this Agreement. This Agreement shall be governed by, and
construed under, the laws of the State of Califomia. The rights and remedies of the
parties are cumulative and the exercise by either party of one or more of such rights or
remedies shall not preclude the exercise by it, at the same or different times, of any
other rights or remedies for the same default or any other default by the other party.
3.12 Attorneys' Fees. If either party to this Agreement is required to initiate or defend, or
is made a party to, any action or proceeding in any way connected with this Agreement,
the party prevailing in the final judgment in such action or proceeding, in addition to
any other relief which may be granted, shall be entitled to litigation costs, including
reasonable attomey's fees and expert witness fees.
3.13 Force Maieure. The time period specified in this Agreement for performance of work
may be extended by City because of any delays due to unforeseeable causes beyond the
control.and without the fault or negligence of Contractor, including, but not restricted
to, acts of God or of the public enemy, unusually severe weather, fires, earthquakes,
floods, epidemics, quarantine restrictions, riots, strikes, freight embargoes, wars,
litigation, and /or acts of any governmental agency, including City, provided that
Contractor shall within ten (10) days of the commencement of such delay notify City in
EIR Services Agreement.DOC 10
• •
E1R Services Agreement
City of Seal Beach and
2.
July, 1997
writing of the causes and length of the delay. If Contractor gives notice of such delay,
City shall ascertain the facts and the extent of delay, and extend the time for performing
the services for the period of the enforced delay, when and if in the iudgement of City,
such delay is justified. City's determination shall be made in writing, and shall be final
and conclusive upon the parties to this Agreement. In no event shall Contractor be
entitled to recover damages against City for any delay in the performance of this
Agreement, however caused. Contractor's sole remedy shall be extension of this
Agreement pursuant to this Section 3.13.
3.14 Non - liability of City Officers and Employees. No officer, ofticial, employee, agent,
representative, or volunteer of City shall be personally liable to Contractor, or any
successor in interest, in the event of any default or breach by City, or for any amount
which may become due to Contractor or its successor, or for breach of any obligation
of the terms of this Agreement.
3.15 Conflict of Interest. No officer, official, employee, agent, representative, or volunteer
of City shall have any financial interest, direct or indirect, in this Agreement, or
participate in any decision relating to this Agreement which affects his or her financial
interest or the financial interest of any corporation, partnership, or association in which
he or she is interested, in violation of any Federal, State, or City statute, ordinance, or
regulation. Contractor shall not employ any such person while this Agreement is in
effect. Contractor warrants that Contractor, its officers and employees, have not, and
will not during the term of this Agreement and for at least twelve (12) months after
performance is complete, accept any employment or consideration from any party that
would constitute a conflict of interest as described in California Government Code
Sections 87100 et seq., and accompanying regulations, as either may be amended from
time to time.
SECTION FOUR: MISCELLANEOUS PROVISIONS
4.1 Records and Reports. Upon request by City, Contractor shall prepare and submit to
City any reports concerning Contractor's performance of the services rendered under
this Agreement. City shall have access, upon reasonable notice, to the books and
records of Contractor related to Contractor's performance of this Agreement in the
event any audit is required. All drawings, documents, and other materials prepared by
Contractor in the performance of this Agreement (i) shall be the property of City and
shall be delivered at no cost to City upon request of City or upon the termination of this
Agreement, and (ii) are confidential and shall not be made available to any individual or
entity without prior written approval of City. Contractor shall keep and maintain all
records and reports related to this Agreement for a period of three (3) years following
termination of this Agreement, and City shall have access to such records in the event
any audit is required.
All documents shall be provided to City in hard copy reproducible form and also in
. Word Perfect 5.0 or 5.1 format. All charts, tables, figures, and maps which are prepared
EIR Services Agreement.DOC 11
• •
• Ell? Services Agreement
City of Seal Beach and
July, 1997
with computer -based mapping or spread -sheet programs shall be provided to City in a
format acceptable to City.
4.2 Notices. Unless otherwise provided herein, all notices required to be delivered under
this Agreement or under applicable law shall be personally delivered, or delivered by
United States mail, prepaid, certified, return receipt requested, or by reputable
document delivery service that provides a receipt showing date and time of delivery.
Notices personally delivered or delivered by a document delivery service shall be
effective upon receipt. Notices delivered by mail shall be effective at 5:00 p.m. on the
second calendar day following dispatch. Notices to City shall be delivered to the
following address, to the attention of City Representative set forth in Paragraph D.1 of
the Fundamental Terms of this Agreement:
To City: City of Seal Beach
211 Eighth Street
Seal Beach, CA 90740
Notices to Contractor shall be delivered to the address set forth below Contractor's
signature on Part I of this Agreement, to the attention of Contractor's Representative
set forth in Paragraph D.2 of the Fundamental Terms of this Agreement. Changes in
the address to be used for receipt of notices shall be effected in accordance with this
Section 4.2.
4.3 Time of Essence. Time is of the essence in the performance of this Agreement.
4.4 Interpretation: Severability. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or .
against either party by reason of the authorship of this Agreement or any other rule of
construction which might otherwise apply. The Section headings are for purposes of
convenience only, and shall not be . construed to limit or extend the meaning of this
Agreement. Each provision of this Agreement shall be severable from the whole. If
. any provision of this Agreement shall be found contrary to law, the remainder of this
Agreement shall continue in full force.
4.5 Corporate Authority. The person(s) executing this Agreement on behalf of the
parties hereto warrant that (i) such party is duly organized and existing, (ii) they are
duly authorized to execute and deliver this Agreement on behalf of said party, (iii) by
so executing this Agreement, such party is formally bound to the provisions of this
Agreement, and (iv) the entering into this Agreement does not violate any provision of
any other Agreement to which said party is bound. •
■
•
E1R Services Agreemeiu.DOC 12
• • EIR Services Agreement
City of Seal Beach and
July, 1997
PART III
SPECIAL PROVISIONS
100. INSUIRANCE. Pursuant to Section 2.1 of Part II ( "General Provisions ") of this
Agreement, the amounts and levels of insurance required shall be as follows:
100.1 General Liability (including premises and operations, contractual liability,
personal injury, independent contractors liability): One Million Dollars ($1,000,000.00)
Single Limit, per occurrence. If commercial general liability insurance or other form
with a general aggregate limit is used, either the general aggregate shall apply
separately to this project, or the general aggregate limit shall be three times the
occurrence limit.
100.2 Automobile Liability (including owned, non - owned, and hired autos): One
Million Dollars ($1,000,000.00), Single limit, per occunence for bodily injury and
property damage.
100.3 Workers Compensation and Employer's Liability: One Million Dollars
($1,000,000.00) per occurrence for injuries incurred in providing services under this
Agreement (if Contractor is required to have per the laws of Califomia).
200. PERSONNEL. shall be assigned to, and shall have direct
responsibility for management of the project. No change shall be made in this
assignment without the prior written approval of City. Consultant may secure, at
Consultant's sole cost and expense, such other persons as may, in the opinion of
Consultant, be needed to comply with the terms of this Agreement. If such persons are
retained by Consultant, Consultant warrants that such persons shall be fully qualified
under applicable State, Federal and local law and industry or professional standards to
perform the services for which Consultant retains them.
In addition to personnel employed directly by Consultant, Consultant shall have the
right to engage such subcontractors as it may deem necessary to the performance of its
services hereunder with the prior approval of the City, which approval shall not be
unreasonably withheld. Contractor warrants that such subcontractors shall be fully qualified
under applicable State, Federal and local law and industry or professional standards to
perform the services for which Consultant retains them.
•
EIR Services Agreement.DOC 13
•
EIR Services Agreement
City of Seal Beach and
July, 1997
PART IV
SCOPE OF WORK
•
EIR Services Agreeim nt.DOC 14
• E1R Services Agreement
. City of Seal Beach and
July, 1997
f
PART V
BUDGET
•
EIR Services AgreemenlDOC 15
./
� ��� . ' e �
`
~~~^ .. .~~.-------- -- '------------------------
PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND
CONFERS mxx RIGHTS UPON THE C- '' HOLDER. F|c�TET*|S CERTIFICATE
Johnson & Higgins ofCalifornia
DOES NOT AK0END.EXTEND ��RA[rsn THE COVERAGE AFFORDED BY THE
Casualty Department, • POLICIES BELOW.
2O2OContury Park East
COMPANIES AFF������U���S/�������o��
; Los Angeles, CA 00067 '/` � ��,•� {�,, �
. Tn|:.(310)552'5931 ! ' . • -.. . ' coMrA �' . , . . ' �� ' • ENTAL -- ' .
. 06510 .L1 - � ---------' '`-� -- � •
� COMPANY B U ^^/`w' =="V"EAC''
: �svnco . LETTER N/A ^^'
� \J� o � n —
P&DCO ' `
• 11OOTOVVN&COUNTRY ROAD STE3U0 COMPANY «� N64-
'ORANGE CA028G8 U �
' --- ' ' ---
' °"~P""` U U
Fs fr.1 D1 A
�n�
' _ U� �����
COMPANY E
• LETTER N/A
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
.
INDCATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR GONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY. BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TsnMa,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
no npsor/wsvn^wns POLICY 'ouc's''son«c POLICY EXPIRATION LIMITS
DATE (mmmooY) DATE (mm/oo^Y)
oewsnxLuxomr, GL 1667e5406 04m1x97 04m1m0 GENERAL AGGREGATE $ 1.000.000
A. X 'ooMMsRom� usws�Luxo/ury pnoou�a'ooM�opwaa. $ 1.000.000
, � ' . -_-
` .. o�/m��xns X OCCUR. �� � . ' �Ennn�Lu ADV. INJURY $ 1.000.000
•
�' ��wsn�mcowrm�ronmpnor % -- '• — -- - • ' EACH OCCURRENCE *_ 1,000,000 '' - ' • ' �` ^ _��o^mxssmn one fire) $ 1,000,000
' MsooPcmnE�n�" n�'�>$
• • . . �
A AUTOMOBILE LIABILITY ouA1snrnnnusK\oo) � ' O*m1mu • ' ' 3 -- ' SINGLE
� 04/01/97 ' � � ��� $ 1,000,000
.' X ANY AUTO � • BUA 166795387 (TX) 0401/87 040100 __
' . ALLowwsoAuroo -
• INJURY m•
SCHEDULED AUTOS - (Per person)
HIRED AUTOS $
NON-OWNED AUTOS (Per acciden
GARAGE LIABILITY
PROPERTY DAMAGE $
EXCESS LIABILITY , EACH OCCURRENCE $
UMBRELLA FORM AGGREGATE $
OTHER THAN UMBRELLA FORM ... ' .'. .;'�
STATUTORY u�r .`� -~x��' �:,:,^
WORKER'S COMPENSATION
EACH ACCIDENT $
AND
DISEASE--POLICY LIMIT $
EMPLOYERS' LIABILITY DISEASE--EACH EMPLOYEE $
OTHER
DESCRIPTION OF OPERATIONS/LOCATIONSNEHICLES/SPECIAL ITEMS (LIMITS MAY BE SUBJECT TO RETENTIONS)
RE: CITY OF SEAL BEACH--ONGOING ENVIRONMENTAL ASSESSMENT nsxvIoco' THE CITY, ITS OFFICERS, OFFICIALS, EMPLOYEES, AGENTS, REPRESEN-
TATIVES & VOLUNTEERS ARE NAMED «o »mozrIowxL INSUREDS UNDER THE GL COVERAGE BUT ONLY AS RESPECTS WORK PERFORMED BY OR ON BEHALF OF
THE NAMED INSURED.
���1 .; :;:;.;: ::;:::: . nag:MAA
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
CITY OF SEAL BEACH �� EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO
MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE
ATTN: LEE VV|TTENBERG
LEFT, BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR
211 EIGHTH STREET
uAamrvop ANY mmoUPON THE oompxw AGENTS onnspnsasw�T/vso
SEALBEACH.CAQU7�O REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE
0 14.1'